f10k_031615.htm
UNITED STATES
SECURITIES AND EXCHANGE COMMISSION
Washington, D.C. 20549
FORM 10-K
 
[X]  annual report pursuant to section 13 or 15(d) of the securities exchange act of 1934
For the fiscal year ended: December 31, 2014
[   ]  transition report pursuant to section 13 or 15(d) of the securities exchange act of 1934
For the transition period from _______________________to ________________________________
Commission file number 1-31993
 
STERLING CONSTRUCTION COMPANY, INC.
(Exact name of registrant as specified in its charter)
 
Delaware
State or other jurisdiction of
incorporation or organization
25-1655321
(I.R.S. Employer
Identification No.)
1800 Hughes Landing Blvd.
The Woodlands, Texas
(Address of principal executive offices)
 
77380
(Zip Code)
 
Registrant’s telephone number, including area code (281) 214-0800
 
Securities registered pursuant to Section 12(b) of the Act:
Name of each exchange on which registered
Title of each class
Common Stock, $0.01 par value per share
(Title of Class)
The NASDAQ Stock Market LLC
 
Securities registered pursuant to section 12(g) of the Act:
None
 
Indicate by check mark if the registrant is a well-known seasoned issuer, as defined in Rule 405 of the Securities Act.
[  ] Yes   [] No
Indicate by check mark if the registrant is not required to file reports pursuant to Section 13 or Section 15(d) of the Act.
[  ] Yes   [] No
Indicate by check mark whether the registrant (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days.
[] Yes  [   ] No
Indicate by check mark whether the registrant has submitted electronically and posted on its corporate Website, if any, every Interactive Data File required to be submitted and posted pursuant to Rule 405 of Regulation S-T during the preceding 12 months (or for such shorter prior that the registrant was required to submit and post such files).
[] ] Yes  [  ] No
Indicate by check mark if disclosure of delinquent filers pursuant to Item 405 of Regulation S-K is not contained herein, and will not be contained, to the best of registrant’s knowledge, in definitive proxy or information statements incorporated by reference in Part III of this Form 10-K or any amendment to this Form 10-K [ ]
Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, or a smaller reporting company.  See definitions of “large accelerated filer,” “accelerated filer” and “smaller reporting company” in Rule 12b-2 of the Exchange Act.        
Large accelerated filer [ ]
Non-accelerated filer [ ] (Do not check if a smaller reporting company)
Accelerated filer []
Smaller reporting company [ ]
Indicate by check mark if the registrant is a shell company (as defined in Rule 12b-2 of the Act). [   ] Yes  [] No
Aggregate market value of the voting and non-voting common equity held by non-affiliates at June 30, 2014: $166,755,548.
At March 6, 2015, the registrant had 18,768,244 shares of common stock outstanding.
 
DOCUMENTS INCORPORATED BY REFERENCE
Portions of the Company’s definitive Proxy Statement to be filed with the Securities and Exchange Commission and delivered to stockholders in connection with the Annual Meeting of Stockholders to be held on May 8, 2015 are incorporated by reference into Part III of this Form 10-K.
 
 

 
 
Sterling Construction Company, Inc.
Annual Report on Form 10-K
Table of Contents
 
PART I
 
   
PART II
 
   
PART III
 
   
PART IV
 
 
 
 
2

 
PART I
 
  Cautionary Comment Regarding Forward-Looking Statements
 
This Report includes statements that are, or may be considered to be, “forward-looking statements” within the meaning of Section 27A of the Securities Act of 1933, as amended, or the Securities Act, and Section 21E of the Securities Exchange Act of 1934, as amended, or the Exchange Act. These forward-looking statements are included throughout this Report, including in the sections entitled “Business,” “Risk Factors,” and “Management’s Discussion and Analysis of Financial Condition and Results of Operations” and relate to matters such as our industry, business strategy, goals and expectations concerning our market position, future operations, margins, profitability, capital expenditures, liquidity and capital resources and other financial and operating information. We have used the words “anticipate,” “assume,” “believe,” “budget,” “continue,” “could,” “estimate,” “expect,” “forecast,” “future,” “intend,” “may,” “plan,” “potential,” “predict,” “project,” “should,” “will,” “would” and similar terms and phrases to identify forward-looking statements in this Report.
 
Forward-looking statements reflect our current expectations as of the date of this Report regarding future events, results or outcomes. These expectations may or may not be realized. Some of these expectations may be based upon assumptions or judgments that prove to be incorrect. In addition, our business and operations involve numerous risks and uncertainties, many of which are beyond our control, that could result in our expectations not being realized or otherwise could materially affect our financial condition, results of operations and cash flows.
 
Actual events, results and outcomes may differ materially from our expectations due to a variety of factors. Although it is not possible to identify all of these factors, they include, among others, the following:
 
·
changes in general economic conditions, including recessions, reductions in federal, state and local government funding for infrastructure services and changes in those governments’ budgets, practices, laws and regulations;
·
delays or difficulties related to the completion of our projects, including additional costs, reductions in revenues or the payment of liquidated damages, or delays or difficulties related to obtaining required governmental permits and approvals;
·
actions of suppliers, subcontractors, design engineers, joint venture partners, customers, competitors, banks, surety companies and others which are beyond our control, including suppliers’, subcontractors’ and joint venture partners’ failure to perform;
·
factors that affect the accuracy of estimates inherent in our bidding for contracts, estimates of backlog, percentage-of-completion accounting policies, including onsite conditions that differ materially from those assumed in our original bid, contract modifications, mechanical problems with our machinery or equipment and effects of other risks discussed in this document;
·
design/build contracts which subject us to the risk of design errors and omissions;
·
cost escalations associated with our contracts, including changes in availability, proximity and cost of materials such as steel, cement, concrete, aggregates, oil, fuel and other construction materials, and cost escalations associated with subcontractors and labor;
·
our dependence on a limited number of significant customers;
·
adverse weather conditions; although we prepare our budgets and bid contracts based on historical rain and snowfall patterns, the incidence of rain, snow, hurricanes, etc., may differ materially from these expectations;
·
the presence of competitors with greater financial resources or lower margin requirements than ours, and the impact of competitive bidders on our ability to obtain new backlog at reasonable margins acceptable to us;
·
our ability to successfully identify, finance, complete and integrate acquisitions;
·
citations issued by any governmental authority, including the Occupational Safety and Health Administration;
·
federal, state and local environmental laws and regulations where non-compliance can result in penalties and/or termination of contracts as well as civil and criminal liability;
·
adverse economic conditions in our markets; and
·
the other factors discussed in more detail in Item 1A. —Risk Factors.
 
In reading this Report, you should consider these factors carefully in evaluating any forward-looking statements and you are cautioned not to place undue reliance on any forward-looking statements. Although we believe that our plans, intentions and expectations reflected in, or suggested by, the forward-looking statements that we make in this Report are reasonable, we can provide no assurance that they will be achieved.
 
The forward-looking statements included in this Report are made only as of the date of this Report, and we undertake no obligation to update any information contained in this Report or to publicly release the results of any revisions to any forward-looking statements to reflect events or circumstances that occur, or that we become aware of after the date of this Report, except as may be required by applicable securities laws.
 
 
3

 
Item 1. Business.
 
Overview of the Company’s Business.
 
Sterling Construction Company, Inc. was founded in 1991 as a Delaware corporation. Our principal executive offices are located at 1800 Hughes Landing Boulevard, Suite 250, The Woodlands, Texas 77380, and our telephone number at this address is (281) 214-0800. Our construction business was founded in 1955 by a predecessor company in Michigan and is now conducted through our subsidiaries which primarily include: Texas Sterling Construction Co., a Delaware corporation, or “TSC”; Road and Highway Builders, LLC, a Nevada limited liability company, or “RHB”; Road and Highway Builders of California, Inc., a California corporation, or “RHBCa”; Ralph L. Wadsworth Construction Company, LLC, a Utah limited liability company, or “RLW”; J. Banicki Construction, Inc., an Arizona corporation, or “JBC”; and Myers & Sons Construction, L.P., a California limited partnership, or “Myers”. The terms “Company,” “Sterling,” and “we” refer to Sterling Construction Company, Inc. and its subsidiaries except when it is clear that those terms mean only the parent company or a particular subsidiary.
 
Sterling is a leading heavy civil construction company that specializes in the building and reconstruction of transportation and water infrastructure projects in Texas, Utah, Nevada, Arizona, California, Hawaii and other states where there are construction opportunities. Its transportation infrastructure projects include highways, roads, bridges and light rail and its water infrastructure projects include water, wastewater and storm drainage systems. Sterling performs the majority of the work required by its contracts with its own crews and equipment.
 
Although we describe our business in this Report in terms of the services we provide, our base of customers and the geographic areas in which we operate, we have concluded that our operations consist of one reportable segment, one operating segment and one reporting unit component, which is heavy civil construction. In making this determination, the Company considered the discrete financial information used by our Chief Operating Decision Maker (“CODM”). Based on this approach, the Company noted that the CODM organizes, evaluates and manages the financial information around each heavy civil construction project when making operating decisions and assessing the Company’s overall performance. Furthermore, we considered that each heavy civil construction project has similar characteristics, includes similar services, has similar types of customers and is subject to similar economic and regulatory environments.
 
Sterling has grown its service profile and geographic reach both organically and through acquisitions. Expansions into Utah, Arizona and California were achieved with the 2009 acquisition of RLW and the 2011 acquisitions of JBC and Myers, respectively. These acquisitions also extended Sterling’s service profiles.
 
Recent Developments.
 
Financial Results for 2014, Operational Issues and Outlook for 2015 Financial Results.
 
In 2014, the Company had an operating loss of $4.2 million and net loss attributable to Sterling common stockholders of $9.8 million. Our gross margins have increased to 4.8% in 2014 from (5.4)% in 2013 and decreased from the 7.5% gross margin experienced in 2012. In 2014, our gross margins continued to be adversely impacted by downward revisions to estimated profitability on projects primarily awarded in Texas; although, to a lesser extent than in the prior year.
 
The majority of our revenues and backlog is derived from fixed unit price contracts. Some of our revenues are derived from lump sum contracts. Fixed unit price contracts require us to provide materials and services at a fixed unit price based on approved quantities irrespective of our actual per unit costs. Lump sum contracts require that the total amount of work be performed for a single price irrespective of our actual costs. As discussed in “Item 1A. Risk Factors,” we realize a profit on our contracts only if we accurately estimate our costs and then successfully control actual costs and avoid cost overruns, and our revenues exceed actual costs. If our cost estimates for a contract are inaccurate, or if we do not execute the contract within our cost estimates, then cost overruns may cause the contract not to be as profitable as we expected or result in a loss, negatively affecting our cash flow, earnings and financial position.
 
While the risks of cost overruns and changes in estimated contract revenues are an inherent part of the construction business, we continue to implement the following changes in order to improve the profitability of our projects, reduce the variability in profitability of our projects in the future and strengthen the internal control environment:
 
·
We continue to change roles and responsibilities to improve functional support and controls when needed.
 
·
We continue to develop management tools designed to improve the estimating process and increase the oversight of that process where needed and continue to refine existing tools.
 
 
4

 
 
·
We continue to implement processes designed to better identify, evaluate and quantify risks for individual projects where needed and continue to refine existing process.
 
·
We continue to improve the methodologies for allocating overhead, indirect costs and equipment costs to individual projects in order to provide more accurate job cost and future bidding estimates.
 
·
We continue to improve the timeliness and content of reporting available to operations management.
 
In addition to the factors discussed above which impact the profitability on individual projects, there are other factors which have adversely affected our ability to secure construction projects at favorable margins. Our highway and related bridge work is generally funded through federal and state authorizations. In recent years, federal and state legislation related to infrastructure spending has been slow to pass. Funding for federal highway projects primarily originate from the Highway Trust Fund where federal motor fuel taxes are the major source of income into the fund. Additional income is provided from the General fund and certain other funds to maintain the solvency of the fund as sources of income remain a challenge. While government spending on highway and related bridge work has not significantly increased in recent years, our backlog has increased $77 million from $687 million at December 31, 2013 to $764 million at December 31, 2014, representing ample work to be bid on within our markets with acceptable gross margins. In addition to highway and related bridge work, we continually look for projects that diversify our book of projects to relieve the continued pressure on our gross margins related to new contract awards from local, state and federal authorities.
 
Our Business Strategy.
 
Key features of our business strategy include:
 
·
Continue to add construction capabilities: by adding capabilities that augment our core contracting and construction competencies, we are able to improve gross margin opportunities and more effectively compete for contracts that might not otherwise be available to us.
·
Expand into new markets and selectively pursue opportunities and strategic acquisitions: we will continue to seek to identify attractive new markets and opportunities in select western, southwestern and southeastern U.S. areas. We will also continue to assess opportunities to extend our service capabilities and expand our markets through acquisitions.
·
Apply core competencies across our markets: we will seek to capitalize on opportunities to export our Texas experience constructing water infrastructure projects and our Nevada earthmoving, aggregates and asphalt paving experience into Utah markets. Similarly, we believe that RLW’s experience with design-build, construction manager and general contractor (“CM/GC”) and other alternative project delivery methods in Utah, and its development of accelerated bridge construction (“ABC”) techniques can enhance opportunities for us in our Texas, California, Arizona and Nevada markets.
·
Increase our market leadership in our core markets: we have a strong presence in a number of markets in Texas, Utah and Nevada and intend to expand our presence in these states as well as Arizona, California, Hawaii and other states where we believe opportunities exist.
·
Position our business for future infrastructure spending: currently there are considerable uncertainties surrounding federal, state and local funding in our markets; however, we believe there is awareness of the need to build, reconstruct and repair our country’s infrastructure, including transportation infrastructure, such as bridges, highways, and mass transit systems and water infrastructure, such as water, wastewater and storm drainage systems. We will continue to build our expertise to capture this infrastructure spending. We also see opportunities to make enhancements to our operations that should yield improving performance over time. These include a tighter integration of the acquisitions we have made over the past several years which should result in cost reductions and better collaboration between business units when pursuing new contract opportunities.
·
Continue to attract, retain and develop our employees: we believe that our employees are key to the successful implementation of our business strategy, and we will continue allocating significant resources in order to attract and retain talented managers and supervisory and field personnel.
 
Our Markets, Customers and Competition.
 
Currently, all our operations are performed within the United States. As such, we rely heavily on federal and state infrastructure spending. Actual appropriations by the U.S. Department of Transportation (“U.S.DOT”) were $38.9 billion for federal highway financial assistance to the states for 2013. Additionally, U.S.DOT had enacted funds for the fiscal year ended September 30, 2014 of $40.1 billion and has requested authority to spend $47.3 billion in fiscal 2015 for highways and bridges.
 
Within the United States, our principal markets are in Texas, Utah, Nevada, Arizona, California and Hawaii, states that management believes benefit from both positive long-term demographic trends as well as a historical commitment to funding transportation and water infrastructure projects. Currently, the Company also has highway construction contracts in Montana, Idaho and Louisiana. According to the 2010 U.S. Census Bureau Information, Texas, Utah, Nevada, Arizona, California and Hawaii are expected to experience population increases of 32.5%, 26.1%, 58.6%, 67.6%, 24.7 and 7.7%, respectively, during the twenty year period between 2010 and 2030. While the near-term funding available for infrastructure spending in these markets is currently limited, management anticipates that long-term population growth and increased spending for infrastructure in these markets will positively affect business opportunities over the coming years.
 
 
5

 
In Texas, our customers include Texas Department of Transportation (“TxDOT”), Texas county and municipal public works departments, regional transit and water authorities, port authorities, school districts, municipal utility districts and the U.S. Corps of Engineers. TxDOT contract awards (“lettings”) for transportation construction projects are estimated to be $9.5 billion in 2015 and $4.2 billion in 2016.
 
Additionally, in Texas, substantial funds for transportation infrastructure spending are also being provided by toll road and regional mobility authorities for construction of toll roads, which provides Sterling with additional construction contracting opportunities; however, such spending could be limited by federal, state and local funding limitations.
 
Texas’ approximately 306,000 miles of roadway is in need of repair and the shale oil traffic has placed an additional burden on the transportation system. In November 2014, a ballot measure known as Proposition 1 was approved which will utilize approximately $1.7 billion from the Texas Economic Stabilization Fund (Rainy Day Fund) for these growing transportation needs. In the November 2013 election, Texans voted in favor of infrastructure spending by passing a water bill. The Proposition 6 water initiative had widespread support in the legislature and 73 percent voted in favor of the amendment. Proposition 6 provides $2 billion from the Rainy Day Fund for low-interest loans to help fund projects in the State Water Plan for the next 50 years.
 
In Utah, our public sector customers include the Utah Department of Transportation (“UDOT”) and the Utah Transit Authority. Spending for highway and bridge construction in Utah was $729 million in 2014, and $741 million has been authorized for 2015. The details of the capital spending budget for 2016 have not been released; however the Utah Governor’s recommendation for total capital spending in 2016 is approximately $687 million. In Utah, we have been competitive, in part, because of successful marketing efforts, design-build and CM/GC capabilities and development of innovative methods for completing projects. Competition for design-build projects is not totally focused on cost factors but is also significantly dependent on successful marketing efforts, reputation, quality of designs and aesthetics. We believe that we were one of the first construction companies to utilize ABC technology to build bridges offsite, move them to their location, and complete their installation in a very short period of time in order to minimize mobility disruptions.
 
In Nevada, we believe that we are a leading asphalt paving contractor on suburban and rural highway projects. Our primary public sector customer is the Nevada Department of Transportation (“NDOT”). Nevada’s budget for construction of roadways and facilities is estimated to be $375 million and $194 million in 2015 and 2016, respectively, compared with expenditures of $557 million in 2014.
 
In Arizona, our principal customers are the Arizona Department of Transportation (“ADOT”) and municipal airport authorities. Arizona’s expenditures for transportation construction were $1.4 billion in 2014, while such expenditures are estimated to be $1.6 billion in each year 2015 and 2016.
 
In California, our principal customer is the California Department of Transportation (“Caltrans”). California’s transportation capital outlays and local assistance were $5.2 billion in 2014, while such expenditures are estimated to be $5.6 billion in 2015 and $5.9 billion in 2016.
 
In Hawaii, our principal customers are the City of Honolulu and the Hawaii Department of Transportation (“HDOT”). Hawaii’s expenditures for transportation construction were $471 million in 2014, while expenditures for 2015 and 2016 are estimated to be $120 million and $133 million, respectively.
 
A significant portion of our contracts pertain to state highway and related bridge work. In 2014, state highway and related bridge work accounted for 48% of our consolidated revenues compared with 62% and 61% in 2013 and 2012, respectively. The majority of the remaining work we perform is for local city municipalities.
 
In the past, we have also completed the construction of certain infrastructure for new light rail systems in Houston, Dallas and Galveston, Texas, and in Salt Lake City, Utah. We anticipate that expenditures in the cities of Houston and San Antonio for road, rail and water infrastructure projects will continue to increase due to steady gains in population in these metropolitan areas as a result of the migration of new residents and the annexation of surrounding communities and due to continuing programs in these metropolitan areas to expand storm water and flood control systems and water delivery systems. We believe that similar municipal civil construction opportunities are available in other municipalities in our major markets.
 
 
6

 
Although we occasionally undertake contracts for private customers, the vast majority of our revenues are attributable to work for public sector customers. Our larger construction projects are typically undertaken from work bid and won as part of a letting through a particular state’s department of transportation. Refer to Note 18 to the consolidated financial statements (references to “Note” or “Notes” are to the Notes to consolidated financial statements for the year ended December 31, 2014, included in this document), for major customers that accounted for 10% or more of total revenue in any of the past three fiscal years. The majority of the services provided to customers are pursuant to contracts awarded through competitive bidding processes.
 
Demand for transportation and water infrastructure depends on a variety of factors, including overall population growth, economic expansion and the vitality of the market areas in which we operate, as well as unique local topographical, structural and environmental issues. In addition to these factors, demand for the replacement of infrastructure is driven by the general aging of infrastructure and the need for technical improvements to achieve more efficient or safer use of infrastructure and resources. Funding for this infrastructure depends on federal, state and local governmental resources, budgets and authorizations.
 
Our competitors include companies that we bid against for construction contracts and compete against for short listings, mandates and joint ventures. We have many competitors of different sizes in all of the markets that we serve, and they include large international, national and regional construction companies as well as many smaller contractors. Historically, the construction business has not typically required large amounts of capital for smaller contracts, which can result in relative ease of market entry for companies possessing acceptable qualifications.
 
Factors influencing our competitiveness include price, our reputation for quality, our innovativeness, our equipment fleet, our work crews, our financial strength, our bonding capacity and prequalification criteria, our knowledge of local markets and conditions, our project management and estimating abilities, our customer relationships, our marketing abilities, our ability to enter into strategic relationships with other contractors and our ability to perform many aspects of each project. Although some of our competitors are larger than we are and may possess greater resources or provide more vertically-integrated services, we believe that we are well-positioned to compete in the markets in which we operate on the basis of the foregoing factors.
 
Based on publicly available information on awarded construction projects, we believe that we are one of the larger participants in each of our Texas, Utah, Nevada, Arizona, California and Hawaii markets. Because we own and maintain most of the equipment required for our contracts and have the key experienced workforce to handle many types of heavy civil construction, we are able to bid competitively on many categories of contracts, especially complex, multi-task projects. In the state highway markets, most of our competitors are large international, national and regional contractors, and individual contracts tend to be larger and require more specialized skills than those in the municipal markets. Some of these competitors have the advantage of being more vertically-integrated, or they specialize in certain types of projects such as construction over water.
 
Our markets have been much more competitive than in the past because of reductions in federal, state and local spending on transportation and water-related infrastructure; bidding by our traditional competitors at what appears to have been break-even or loss margins; the entry of new competitors from other states and the expansion of foreign competitors into our markets. While our business includes only minimal residential and commercial infrastructure work, the severe fall-off in new projects in those markets has resulted in some residential and commercial infrastructure contractors bidding on smaller public sector transportation and water infrastructure projects, sometimes at bid levels below our break-even pricing, thus increasing competition and creating downward pressure on the bid prices in our markets. These factors have compressed the profitability on many new projects where we submitted successful bids.
 
These and other factors have adversely affected the levels of transportation and water infrastructure capital awards and expenditures in our markets, reducing opportunities to replace backlog at reasonable margins and increasing competition for new projects. However, we believe that the Company is well-established in our particular markets and has a fleet of modern equipment that gives us the ability to perform a broad range of work which will allow us to weather current market conditions and to continue to compete successfully for projects as they become available at acceptable profit margin levels.
 
Backlog.
 
Backlog is the revenue we expect to earn in future periods on our construction projects. However, low bid awards not officially awarded are excluded from backlog. As the construction on our projects progresses, we increase or decrease backlog to take into account our estimates of the effects of changes in estimated quantities, changed conditions, change orders and other variations from initially anticipated contract revenues, including completion penalties and incentives. At December 31, 2014, our backlog was $764 million.
 
 
7

 
Substantially all of the contracts in our contract backlog may be canceled at the election of the customer; however, we have not been materially adversely affected by contract cancellations or modifications in the past. See the section below entitled, “Contracts — Contract Management Process.”
 
Construction Delivery Methods.
 
Alternative construction delivery methods describe different contractual and responsibility relationships among the owner, the builder and the designer of a project. There are three primary construction delivery methods: design-bid-build, design-build and construction management.
 
The traditional method by which the majority of our projects have historically been completed is design-bid-build. Under this type of construction delivery, the owner hires a design engineer to design the project and then solicits bids from construction firms and typically awards the contract to build the pre-designed project to the lowest qualifying bidder. The contractor to whom the project is awarded becomes the general contractor and is responsible for completing the project in accordance with the owner’s designs using the contractor’s own employees or resources, or subcontractors. Projects under this method are typically fixed unit price contracts.
 
Design-build is increasingly being used by public entities as a method of project delivery. Unlike traditional projects where the owner first hires a design firm or designs a project itself and then puts the project out to bid for construction, design-build projects provide the owner with a single point of responsibility and a single contact for both final design and construction. The owner selects a builder who hires the design team as required and construction typically starts before the design is complete. This project delivery method is typically undertaken through either fixed unit price contracts or lump sum contracts, and price is not the only determining factor used by the owner when selecting a particular contractor.
 
Construction management is a newer method of delivering a project whereby a contractor agrees to manage a project for the owner for an agreed-upon fee, which may be fixed or may vary based upon negotiated factors. The owner of the project typically hires the contractor as a construction manager early in the design phase of the project. The construction manager works with the design team to help ensure that the design is something that can in fact be built within the owner’s desired cost and other parameters and that the ultimate construction contractor will be able to understand the design drawings and specifications. There are two basic types of construction management: construction manager as advisor and construction manager at risk. In the construction manager as advisor type of arrangement, the construction manager acts as a technical consultant to the owner of the project and has no legal responsibility for the performance of the actual construction work. In the construction manager at risk type of arrangement, the construction manager becomes the prime contractor during the construction phase and makes a determination as to which portions of the work will be self-performed and which will be performed through subcontracts. In either type of construction management process, portions of a project are often submitted for bid during the course of the construction manager relationship, with the construction manager bidding, and oftentimes having the first right to bid, on portions of the project.
 
Contracts.
 
Types of Contracts.
 
We provide our services primarily by using traditional general contracting arrangements, including fixed-unit price contracts, lump sum contracts and cost-plus contracts.
 
Fixed unit price contracts are generally used in competitively-bid public civil construction contracts. Contractors under fixed unit price contracts are generally committed to provide all of the resources required to complete the contract for a fixed price per unit. These contracts are generally subject to negotiated change orders, frequently due to differences in site conditions from those initially anticipated or asserted by the customer. Some fixed unit price contracts provide for penalties, if the contract is not completed on time, or incentives, if it is completed ahead of schedule.
 
Under a lump sum contract, the contractor typically agrees to deliver a completed project in accordance with the contract’s requirements for a specific price, and the customer agrees to pay the price according to a negotiated payment schedule. In developing a lump sum bid, the contractor estimates the costs of labor, subcontracts and materials and adds an amount for overhead and profit. The amount of the profit included in the bid is based on the contractor’s assessment of risk and other factors such as availability of resources. If the actual costs of labor, subcontracts, materials and overhead are higher than the contractor’s estimate, the profit will be reduced or become a loss; if the actual costs are lower, the contractor may earn more profit.
 
In a cost plus contract, the owner of a project generally agrees to pay the cost of all of the contractor’s labor, subcontracts and materials plus an amount for contractor overhead and profit (usually as a percentage of the labor, subcontracts and material cost). If actual costs are lower than the estimate, the owner benefits from the cost savings. If actual costs are higher than the estimate, the owner bears the economic burden of the additional costs.
 
 
8

 
Contract Management Process.
 
We identify potential contracts from a variety of sources, including through subscriber services that notify us of contracts out for bid; through advertisements by federal, state and local governmental entities; through our business development efforts; through contacts at government agencies; and through meetings with other participants in the construction industry. After determining which contracts are available, we decide which contracts to pursue based on such factors as the relevant skills required, the contract size and duration, the availability of our personnel and equipment, the size and makeup of our current backlog, our competitive advantages and disadvantages, prior experience, the contracting agency or customer, the source of contract funding, geographic location, likely competition, construction risks, gross margin opportunities, penalties or incentives and the type of contract.
 
As a condition to pursuing some contracts, we are required to complete a prequalification process with the applicable agency or customer. Some customers, such as state departments of transportation, require yearly prequalification, and some other customers have experience requirements specific to the contract. The prequalification process generally limits bidders to those companies with the operational experience and financial capability to effectively complete the particular contract in accordance with the plans, specifications and construction schedule.
 
There are several factors that can create variability in contract performance and financial results compared to our bid assumptions on a contract. The most significant of these include the completeness and accuracy of our original bid analysis, recognition of costs associated with added scope changes, extended overhead due to customer and weather delays, subcontractor availability and performance issues, changes in productivity expectations, site conditions that differ from those assumed in the original bid, and changes in the availability and proximity of materials. In addition, our original bids for some contracts are based on the contract customer’s estimates of the quantities needed to complete a contract. If the quantities ultimately needed are different, our backlog and financial performance on the contract will change. All of these factors can lead to inefficiencies in contract performance, which can increase costs and lower profits. Conversely, if any of these or other factors is more favorable than the assumptions in our bid, contract profitability can improve. Design-build projects carry additional risks such as design error risk and the risk associated with estimating quantities and prices before the project design is completed. Design errors may result in higher than anticipated construction costs and additional liability to the contract owner. Although we manage this additional risk by adding contingencies to our bid amounts, obtaining errors and omissions insurance and obtaining indemnifications from our design consultants where possible, there is no guarantee that these risk management strategies will always be successful. Generally, gross margins included in bids on design-build contracts are higher than for other types of contracts due to the higher risks involved.
 
The estimating process for our traditional fixed unit price competitive bid contracts typically involves three phases. Initially, we consider the level of anticipated competition and our available resources for the prospective project. If we then decide to continue considering a project, we undertake the second phase of the contract process and spend several weeks performing a detailed review of the plans and specifications, summarizing the various types of work involved and related estimated quantities, determining the contract duration and schedule and highlighting the unique and riskier aspects of the contract. Concurrent with this process, we estimate the cost and availability of labor, material, equipment, subcontractors and the project team required to complete the contract on time and in accordance with the plans and specifications. Substantially all of our estimates are made on a per-unit basis for each line item, and it is not unusual for an estimate to contain over 300 line items. The final phase consists of a detailed review of the estimate by management, including, among other things, assumptions regarding cost, approach, means and methods, productivity, risk and the estimated profit margin. This profit amount will vary according to management’s perception of the degree of difficulty of the contract, the current competitive climate and the size, availability of resources and makeup of our backlog. Our project managers are intimately involved throughout the estimating and construction process so that contract issues, and risks, can be understood and addressed generally on a timely basis.
 
Although the factors described above are relevant in determining the appropriate amount to bid, the contracting process is managed differently if the project is to be performed on a design-build basis or a CM/GC basis. For design-build projects, we assemble a team that may include project managers, engineers, quality managers and surveyors, to learn about a project that we have identified as one on which we may desire to bid. For some projects, pre-qualification for the project is required where each contractor and/or contracting team prepares a description of financial strengths, past experience on similar types of projects, safety record and the persons who will be on the project management and design team, after which, the customer will usually announce a short list of three to five contractors to respond to a request for proposal, generally within three months. Utilizing the limited design specifications provided by the customer, we generally meet weekly over a two to three month period with design engineers to generate a bid containing quantities, prices, timing and a description of our approach for completing the project. The customer then reviews the bids and selects the one that has the best value, and considers factors such as contractor qualifications, the time estimated to complete the project and the price bid.
 
 
9

 
For our CM/GC projects, the customer typically sends out a request for proposal to general contractors for a project. The customer scores each contractor that submits a bid based on the unit prices submitted for five to twenty items that comprise approximately 10% to 20% of the project design, the profit margin proposed, the experience of the contractor for similar types of projects, the contractor’s approach to completing the specific project and whether the contractor understands the CM/GC process. A committee reviews each bid and determines the best value winner to be the general contractor. If we are the winning general contractor, we work with the customer and the engineer to design the project. As various phases of the project are designed, we usually submit bids to construct phases of the project for which we are qualified. In some situations, we also solicit bids from other construction contractors. If we are the lower bidder, we are awarded a contract for that phase. In other situations, if our bid is close to the cost estimates determined by the customer and the engineer, then we will generally be awarded the contract for a particular phase; otherwise, the customer negotiates with us on an appropriate contract price; and if those negotiations are not successful, then the customer can terminate our contract.
 
To manage risks of changes in material prices and subcontracting costs used in tendering bids for construction contracts, we generally obtain firm price quotations from our suppliers and subcontractors, except for fuel and trucking, before submitting a bid. For fixed unit price contracts, these quotations do not include any quantity guarantees, and we have no obligation for materials or subcontract services beyond those required to complete the respective contracts that we are awarded for which quotations have been provided. For design-build and CM/GC projects, lump sum subcontracts are often executed with subcontractors.
 
During the construction phase of a contract, we monitor our progress by comparing actual costs incurred and quantities completed to date with budgeted amounts and the contract schedule, and periodically prepare an updated estimate of total forecasted revenue, cost and expected profit for the contract.
 
During the normal course of most contracts, the customer, and sometimes the contractor, initiates modifications or changes to the original contract to reflect, among other things, changes in quantities, specifications or design, method or manner of performance, facilities, materials, site conditions and the period for completion of the work. In many cases, final contract quantities may differ from those specified by the customer. Generally, the scope and price of these modifications are documented in a “change order” to the original contract and reviewed, approved and paid in accordance with the normal change order provisions of the contract. We are often required to perform extra or change order work under our fixed unit price contracts as directed by the customer even if the customer has not agreed in advance on the scope or price of the work to be performed. This process may result in disputes over whether the work performed is beyond the scope of the work included in the original contract plans and specifications or, even if the customer agrees that the work performed qualifies as extra work, the price that the customer is willing to pay for the extra work. These disputes may not be settled to our satisfaction. Even when the customer agrees to pay for the extra work, we may be required to fund the cost of the work for a lengthy period of time until the change order is approved and funded by the customer. In addition, any delay caused by the extra work may adversely impact the timely scheduling of other work on the contract (or on other contracts) and our ability to meet contract milestone dates.
 
The process for resolving contract claims varies from one contract to another but, in general, we attempt to resolve claims at the project supervisory level through the normal change order process or, if necessary, with higher levels of management within our organization and the customer’s organization. Regardless of the process, when a potential claim arises on a contract, we typically have the contractual obligation to perform the work and must incur the related costs. We do not recoup the costs unless and until the claim is resolved, which could take a significant amount of time.
 
Most of our construction contracts provide for termination of the contract for the convenience of the customer, with provisions to pay us only for work performed through the date of termination. Our backlog and results of operations have not been materially adversely affected by these provisions in the past.
 
We act as the prime contractor on the majority of the construction contracts that we undertake. We generally complete the majority of the work on our contracts with our own resources, and we typically subcontract only specialized activities, such as traffic control, electrical systems, signage, trucking and earthmoving. As the prime contractor, we are responsible for the performance of the entire contract, including subcontract work. Thus, we are subject to increased costs associated with the failure of one or more subcontractors to perform as anticipated. We manage this risk by reviewing the size of the subcontract, the financial stability of and prior experience with the subcontractor and other factors. Although we generally do not require that our subcontractors furnish a bond or other type of security to guarantee their performance, we require performance and payment bonds on some specialized or large subcontract portions of our contracts. Disadvantaged business enterprise regulations require us to use our best efforts to subcontract a specified portion of contract work performed for governmental entities to certain types of subcontractors, including minority- and women-owned businesses. We have not experienced significant costs associated with subcontractor performance issues in the past.
 
 
10

 
Joint Ventures.
 
We participate in joint ventures with other large construction companies and other partners, typically for large, technically complex projects, including design-build projects, when it is desirable to share risk and resources in order to seek a competitive advantage or when the project is too large for us to obtain sufficient bonding. Joint venture partners typically provide independently prepared estimates, furnish employees and equipment, enhance bonding capacity and often also bring local knowledge and expertise. We select our joint venture partners based on our analysis of their construction and financial capabilities, expertise in the type of work to be performed and past working relationships with us, among other criteria.
 
Under a joint venture agreement, one partner is typically designated as the sponsor or manager. The sponsoring partner typically provides all administrative, accounting and most of the project management support for the project and generally receives a fee from the joint venture for these services. We have been designated as the sponsoring partner in certain of our current joint venture projects and are a non-sponsoring partner in others.
 
Joint venture contracts with project owners typically impose joint and several liability on the joint venture partners. Although our agreements with our joint venture partners provide that each party will assume and pay its share of any losses resulting from a project, if one of our partners is unable to pay its share, we would be fully liable under our contract with the project owner. Circumstances that could lead to a loss under these guarantee arrangements include a partner’s inability to contribute additional funds to the venture in the event that the project incurs a loss or additional costs that we could incur should the partner fail to provide the services and resources toward project completion that had been committed to in the joint venture agreement.
 
Insurance and Bonding.
 
All of our buildings and equipment are covered by insurance, at levels which our management believes to be adequate. In addition, we maintain general liability and excess liability insurance, workers’ compensation insurance and auto insurance all in amounts consistent with our risk of loss and industry practice.
 
As a normal part of the construction business, we are generally required to provide various types of surety and payment bonds that provide an additional measure of security for our performance under the contract. Typically, a bidder for a contract must post a bid bond, generally for 5% to 10% of the amount bid, and on winning the bid, must post a performance and payment bond for 100% of the contract amount. Upon completion of a contract, before receiving final payment on the contract, a contractor must post a maintenance bond for generally 1% of the contract amount for one to two years. Our ability to obtain surety bonds depends upon our capitalization, working capital, aggregate contract size, past performance, management expertise and external factors, including the capacity of the overall surety market. Surety companies consider such factors in light of the amount of our backlog that we have currently bonded and their current underwriting standards, which may change from time to time. As is customary, we have agreed to indemnify our bonding company for all losses incurred by it in connection with bonds that are issued, and we have granted our bonding company a security interest in certain assets, including accounts receivable, as collateral for such obligation.
 
Government and Environmental Regulations.
 
Our operations are subject to compliance with numerous regulatory requirements of federal, state and local agencies and authorities, including regulations concerning safety, wage and hour, and other labor issues, immigration controls, vehicle and equipment operations and other aspects of our business. For example, our construction operations are subject to the requirements of the Occupational Safety and Health Act, or OSHA, and comparable state laws directed toward the protection of employees. In addition, most of our construction contracts are entered into with public authorities, and these contracts frequently impose additional governmental requirements, including requirements regarding labor relations and subcontracting with designated classes of disadvantaged businesses.
 
All of our operations are also subject to federal, state and local laws and regulations relating to the environment, including those relating to discharges into air, water and land, climate change, the handling and disposal of solid and hazardous waste, the handling of underground storage tanks and the cleanup of properties affected by hazardous substances. For example, we must apply water or chemicals to reduce dust on road construction projects and to contain contaminants in storm run-off water at construction sites. In certain circumstances, we may also be required to hire subcontractors to dispose of hazardous wastes encountered on a project in accordance with a plan approved in advance by the customer. Certain environmental laws impose substantial penalties for non-compliance and others, such as the federal Comprehensive Environmental Response, Compensation and Liability Act, or CERCLA, impose strict and retroactive joint and several liability upon persons responsible for releases of hazardous substances.
 
CERCLA and comparable state laws impose liability, without regard to fault or the legality of the original conduct, on certain classes of persons that contributed to the release of a “hazardous substance” into the environment. These persons include the owner or operator of the site where the release occurred and companies that disposed or arranged for the disposal of the hazardous substances found at the site. Under CERCLA, these persons may be subject to joint and several liability for the costs of cleaning up the hazardous substances that have been released into the environment, for damages to natural resources and for the costs of certain health studies. CERCLA also authorizes the federal Environmental Protection Agency, or EPA, and, in some instances, third parties, to act in response to threats to the public health or the environment and to seek to recover from the responsible classes of persons the costs they incur.
 
 
11

 
Solid wastes, which may include hazardous wastes, are subject to the requirements of the Federal Solid Waste Disposal Act, the Federal Resource Conservation and Recovery Act, referred to as RCRA, and comparable state statutes. Although we do not generate solid waste, we occasionally dispose of solid waste on behalf of customers. From time to time, the EPA considers the adoption of stricter disposal standards for non-hazardous wastes. Moreover, it is possible that additional wastes will in the future be designated as “hazardous wastes.” Hazardous wastes are subject to more rigorous and costly disposal requirements than are non-hazardous wastes.
 
We continually evaluate whether we must take additional steps at our locations to ensure compliance with environmental laws. While compliance with applicable regulatory requirements has not materially adversely affected our operations in the past, there can be no assurance that these requirements will not change and that compliance will not adversely affect our operations in the future. That tighter regulation for the protection of the environment and other factors may make it more difficult to obtain new permits and renewal of existing permits may be subject to more restrictive conditions than currently exist.
 
Employees.
 
As of December 31, 2014, the Company had approximately 1,799 employees, including 1,498 field personnel. Of our 1,498 field employees, 475 were union members in Nevada, Arizona, California and Hawaii, and these union employees are represented by 16 unions.
 
Our business is dependent upon a readily available supply of management, supervisory and field personnel. Substantially all of our employees are hired on a permanent basis; however, as is typical in the construction industry, we experience a high degree of turnover as a result of construction projects being completed. In the past, we have been able to attract sufficient numbers of personnel to support the growth of our operations. However, we have recently experienced intense competition for craft labor, primarily in Texas.
 
We conduct extensive safety training programs, which have allowed us to maintain a high safety level at our worksites. All newly-hired employees undergo an initial safety orientation, and for certain types of projects, we conduct specific hazard training programs. Our project foremen and superintendents conduct weekly on-site safety meetings, and our full-time safety inspectors make random site safety inspections and perform assessments and training if infractions are discovered. In addition, all of our superintendents and project managers are required to complete an OSHA-approved safety course.
 
Access to Company’s Filings.
 
The Company maintains a website at www.strlco.com on which our latest Annual Report on Form 10-K, recent Quarterly Reports on Form 10-Q, recent Current Reports on Form 8-K, any amendments to those filings, and other filings may be accessed free of charge, some directly on the website and others through a link to the Securities and Exchange Commission’s (“SEC”) website (www.sec.gov) where those reports are filed. Our website also has recent press releases, the Company’s Code of Business Conduct & Ethics, the charters of the Audit Committee, Compensation Committee, and Corporate Governance & Nominating Committee of the Board of Directors and information on the Company’s “whistle-blower” procedures. Our website content is made available for information purposes only. It should not be relied upon for investment purposes, and none of the information on the website is incorporated into this Report by this reference to it.
 
Item 1A. Risk Factors.
 
The risks described below are those we believe to be the material risks we face. Any of the risk factors described below could significantly and adversely affect our business, prospects, financial condition, results of operations and cash flows.
 
Risks Relating to Our Business.
 
If we are unable to accurately estimate the overall risks, requirements or costs when we bid on or negotiate a contract that is ultimately awarded to us, we may achieve a lower than anticipated profit or incur a loss on the contract.
 
The majority of our revenues and backlog are derived from fixed unit price contracts. Some of our revenues are derived from lump sum contracts. Fixed unit price contracts require us to provide materials and services at a fixed unit price based on approved quantities irrespective of our actual per unit costs. Lump sum contracts require that the total amount of work be performed for a single price irrespective of our actual per unit costs. We realize a profit on our contracts only if we accurately estimate our costs and then successfully control actual costs and avoid cost overruns, and our revenues exceed actual costs. If our cost estimates for a contract are inaccurate, or if we do not execute the contract within our cost estimates, then cost overruns may cause us to incur losses or cause the contract not to be as profitable as we expected. The final results under these types of contracts could negatively affect our cash flow, earnings and financial position.
 
 
12

 
 
The costs incurred and gross profit realized on our contracts can vary, sometimes substantially, from our original projections due to a variety of factors, including, but not limited to:
 
·
onsite conditions that differ from those assumed in the original bid or contract;
·
failure to include required materials or work in a bid, or the failure to estimate properly the quantities or costs needed to complete a lump sum contract;
·
delays caused by weather conditions;
·
contract or project modifications creating unanticipated costs not covered by change orders;
·
changes in availability, proximity and costs of materials, including steel, concrete, aggregates and other construction materials (such as stone, gravel, sand and oil for asphalt paving), as well as fuel and lubricants for our equipment;
·
inability to predict the costs of accessing and producing aggregates and purchasing oil required for asphalt paving projects;
·
availability and skill level of workers in the geographic location of a project;
·
failure by our suppliers, subcontractors, designers, engineers, joint venture partners or customers to perform their obligations;
·
fraud, theft or other improper activities by our suppliers, subcontractors, designers, engineers, joint venture partners or customers or our own personnel;
·
mechanical problems with our machinery or equipment;
·
citations issued by any governmental authority, including the Occupational Safety and Health Administration;
·
difficulties in obtaining required governmental permits or approvals;
·
changes in applicable laws and regulations;
·
delays in quickly identifying and taking measures to address issues which arise during production; and
·
claims or demands from third parties for alleged damages arising from the design, construction or use and operation of a project of which our work is part.
 
Many of our contracts with public sector customers contain provisions that purport to shift some or all of the above risks from the customer to us, even in cases where the customer is partly at fault. Our experience has often been that public sector customers have been willing to negotiate equitable adjustments in the contract compensation or completion time provisions if unexpected circumstances arise. However, public sector customers may seek to impose contractual risk-shifting provisions more aggressively, which could increase risks and adversely affect our cash flow, earnings and financial position.
 
We may be unable to grow our revenues and increase our profitability.
 
Our revenue has grown rapidly in recent years, in part through acquisitions that expanded our geographical footprint. We may be unable to grow our revenues for a variety of reasons, including decreased government funding for infrastructure projects, limits on additional growth in our current markets, reduced spending by our customers, an increased number of competitors, less success in competitive bidding for contracts, limitations on access to necessary working capital and investment capital to sustain growth, limitations on access to bonding to support increased contracts and operations, inability to hire and retain essential personnel and to acquire equipment to support growth, and inability to identify acquisition candidates and successfully acquire and integrate them into our business. A substantial decline in our revenue could have a material adverse effect on our financial condition and results of operations if we are unable to also reduce our operating expenses. See “Recent Developments ― Financial Results for 2014, Operational Issues and Outlook for 2015 Financial Results” above for further discussion of the impact on our financial results.
 
Economic downturns or reductions in government funding of infrastructure projects could reduce our revenues and profits and have a material adverse effect on our results of operations.
 
Our business is highly dependent on the amount and timing of infrastructure work funded by various governmental entities, which, in turn, depends on the overall condition of the economy, the need for new or replacement infrastructure, the priorities placed on various projects funded by governmental entities and federal, state or local government spending levels. Spending on infrastructure could decline for numerous reasons, including decreased revenues received by state and local governments for spending on such projects, including federal funding. The most recent recession caused a nationwide decline in home sales and an increase in foreclosures, which correspondingly resulted in decreases in property taxes and some other local taxes, which are among the sources of funding for municipal road, bridge and water infrastructure construction. State spending on highway and other projects can be adversely affected by decreases or delays in, or uncertainties regarding, federal highway funding, which could adversely affect us. We are reliant upon contracts with state transportation departments for a significant portion of our revenues.
 
 
13

 
See “Business−Our Markets, Customers and Competition” above for a more detailed discussion of our markets and their funding sources.
 
We operate in Texas, Utah, Nevada, Arizona, California, Hawaii and to a lesser extent in other states, and adverse changes to the economy and business environment in those states have had an adverse effect on, and could continue to adversely affect, our operations, which could lead to lower revenues and reduced profitability.
 
Because of this concentration in specific geographic locations, we are susceptible to fluctuations in our business caused by adverse economic or other conditions in these regions, including natural or other disasters. The stagnant or depressed economy, to varying degrees, in Texas, Utah, Nevada, Arizona, California and Hawaii have adversely affected, and could continue to adversely effect, our business and results of operations.
 
The cancellation of significant contracts or our disqualification from bidding for new contracts could reduce our revenues and profits and have a material adverse effect on our results of operations.
 
Contracts that we enter into with governmental entities can usually be canceled at any time by them with payment only for the work already completed. In addition, we could be prohibited from bidding on certain governmental contracts if we fail to maintain qualifications required by those entities. A cancellation of an unfinished contract or our debarment from the bidding process could cause our equipment and work crews to be idled for a significant period of time until other comparable work becomes available, which could have a material adverse effect on our business and results of operations.
 
Our growth strategy involves a number of risks.
 
While for a number of years we have pursued revenue and profit growth through the acquisition of companies and assets that enabled us to expand our project skill-sets and capabilities, enlarge our geographic markets, add experienced management and enhance our ability to bid on larger contracts, we may be unable or unwilling to continue to implement this strategy if we cannot reach agreements for potential acquisitions on acceptable terms or for other reasons. Risks related to growth, including growth through acquisitions, include:
 
·
difficulties in the integration of operations and systems;
·
difficulties applying our expertise in one market into another market;
·
regulatory requirements that impose restrictions on bidding for certain projects because of historical operations by Sterling or the acquired company;
·
the key personnel, customers and project partners of the acquired company may terminate or diminish their relationships with the acquired company;
·
we may experience additional financial and accounting challenges and complexities in areas such as tax planning and financial reporting;
·
we may assume or be held liable for risks and liabilities (including for environmental-related costs and liabilities) as a result of our acquisitions, some of which we may not discover during our due diligence;
·
we may not adequately anticipate competitive and other market factors applicable to the acquired company;
·
our ongoing business may be disrupted or receive insufficient management attention; and
·
we may not be able to realize cost savings or other financial benefits we anticipated or we may not realize the anticipated benefits in the time frame that we expected.
 
Future growth, including growth through acquisitions, may require us to obtain additional equity or debt financing, as well as additional surety bonding capacity, which may not be available on terms acceptable to us or at all. Moreover, to the extent that any acquisition results in additional goodwill, it will reduce our tangible net worth, which might have an adverse effect on our credit and bonding capacity.
 
Management may have difficulty implementing its business strategy.
 
We have recently experienced significant losses primarily related to projects constructed in Texas. If management is unable to timely implement its business strategy to return to profitability in its Texas, or other markets, our results of operations, cash flows and shareholder returns could be adversely affected. In addition, if a return to profitability does not occur within the time frame that we anticipate, or if we continue to incur losses in our Texas, or other markets, we may not have sufficient working capital to timely complete our construction projects. If adequate funds are not available, or are not available on acceptable terms, to alleviate our working capital constraints as we execute our business strategy to return to profitability we may need to liquidate assets, sell our owner’s interest in subsidiaries, or take other measures to provide sufficient working capital to continue our operations.
 
 
14

 
Our industry is highly competitive, with a variety of companies competing against us, and our failure to compete effectively could reduce the number of new contracts awarded to us or adversely affect our margins on contracts awarded.
 
In the past, a majority of the contracts on which we bid were awarded through a competitive bid process, with awards generally being made to the lowest bidder, but sometimes recognizing other factors, such as shorter contract schedules or prior experience with the customer. For our design-build, CM/GC and other alternative methods of delivering projects, reputation, marketing efforts, quality of design and minimizing public inconvenience are also significant factors considered in awarding contracts, in addition to cost. Within our markets, we compete with many international, national, regional and local construction firms. Some of these competitors have achieved greater market penetration than we have in the markets in which we compete, and some may have greater financial and other resources than we do. In addition, there are a number of international and national companies in our industry that are larger than we are and that, if they so desire, could establish a presence in our markets and compete with us for contracts.
 
In some markets where residential and commercial projects have significantly diminished, the bidding environment in our markets has been much more competitive as construction companies that lack available work in those markets have begun bidding on projects in our markets, sometimes at bid levels below our break-even pricing. In addition, traditional competitors on larger transportation and water infrastructure projects also appear to have been bidding at less than normal margins, and in some cases at below our break-even pricing, in order to replenish their backlogs. As a result, we may need to accept lower contract margins in order to compete against competitors that have the ability to accept awards at lower prices or have a pre-existing relationship with a customer.
 
In addition, if the use of design-build, CM/GC and other alternative project delivery methods continues to increase and we are not able to further develop our capabilities and reputation in connection with these alternative delivery methods, we will be at a competitive disadvantage, which may have a material adverse effect on our financial position, results of operations, cash flows and prospects. If we are unable to compete successfully in our markets, our relative market share and profits could also be reduced.
 
Our dependence on subcontractors and suppliers of materials (including petroleum-based products) could increase our costs and impair our ability to complete contracts on a timely basis or at all, which would adversely affect our profits and cash flow.
 
We rely on third-party subcontractors to perform some of the work on many of our contracts. We generally do not bid on contracts unless we have the necessary subcontractors committed for the anticipated scope of the contract and at prices that we have included in our bid, except in some instances for trucking arrangements. Therefore, to the extent that we cannot engage subcontractors, our ability to bid for contracts may be impaired. In addition, if a subcontractor is unable to deliver its services according to the negotiated terms for any reason, including the deterioration of its financial condition, we may suffer delays and be required to purchase the services from another source at a higher price or incur other unanticipated costs. This may reduce the profit to be realized, or result in a loss, on a contract.
 
We also rely on third-party suppliers to provide most of the materials (including aggregates, cement, asphalt, concrete, steel, pipe, oil and fuel) for our contracts, except in Nevada where we source and produce some of the aggregates we use from quarries in which we have mining rights. We do not own or operate any quarries in Texas, Utah, Arizona, California, or Hawaii. We normally do not bid on contracts unless we have commitments from suppliers for the materials and subcontractors for certain of the services required to complete the contract and at prices that we have included in our bid, except for some construction projects in Nevada where we use aggregates from quarries in which we have mining rights. Thus, to the extent that we cannot obtain commitments from our suppliers for materials and subcontractors for certain of the services, our ability to bid for contracts may be impaired. In addition, if a supplier or subcontractor is unable to deliver materials or services according to the negotiated terms of a supply/services agreement for any reason, including the deterioration of its financial condition, we may suffer delays and be required to purchase the materials/services from another source at a higher price or incur other unanticipated costs. This may reduce the profit to be realized, or result in a loss, on a contract.
 
Diesel fuel and other petroleum-based products are utilized to operate the plants and equipment on which we rely to perform our construction contracts. In addition, our asphalt plants and suppliers use oil in combination with aggregates to produce asphalt used in our road and highway construction projects. Decreased supplies of such products relative to demand, unavailability of petroleum supplies due to refinery turnarounds, higher prices charged for petroleum based products and other factors can increase the cost of such products. Future increases in the costs of fuel and other petroleum-based products used in our business, particularly if a bid has been submitted for a contract and the costs of such products have been estimated at amounts less than the actual costs thereof, could result in a lower profit, or a loss, on a contract.
 
 
15

 
We may not accurately assess the quality, and we may not accurately estimate the quality, quantity, availability and cost, of aggregates we plan to produce, particularly for projects in rural areas of Nevada, which could have a material adverse effect on our results of operations.
 
Particularly for projects in rural areas of Nevada, we typically estimate the quality, quantity, availability and cost for anticipated aggregate sources that we have not previously used to produce aggregates, which increases the risk that our estimates may be inaccurate. Inaccuracies in our estimates regarding aggregates could result in significantly higher costs to supply aggregates needed for our projects, as well as potential delays and other inefficiencies. As a result, our failure to accurately assess the quality, quantity, availability and cost of aggregates could cause us to incur losses, which could materially adversely affect our results of operations.
 
If we are unable to attract and retain key personnel and skilled labor, or if we encounter labor difficulties, our ability to bid for and successfully complete contracts may be negatively impacted.
 
Our ability to attract and retain reliable, qualified personnel is a significant factor that enables us to successfully bid for and profitably complete our work. This includes members of our management, project managers, estimators, supervisors, foremen, equipment operators and laborers. The loss of the services of any of our management could have a material adverse effect on us. Our future success will also depend on our ability to hire and retain, or to attract when needed, highly-skilled personnel. If competition for these employees is intense, we could experience difficulty hiring and retaining the personnel necessary to support our business. If we do not succeed in retaining our current employees and attracting, developing and retaining new highly-skilled employees, our reputation may be harmed and our operations and future earnings may be negatively impacted.
 
We rely heavily on immigrant labor. We have taken steps that we believe are sufficient and appropriate to ensure compliance with immigration laws. However, we cannot provide assurance that we have identified, or will identify in the future, all illegal immigrants who work for us. Our failure to identify illegal immigrants who work for us may result in fines or other penalties being imposed upon us, which could have a material adverse effect on our operations, results of operations and financial condition.
 
In Nevada, California and Hawaii, a substantial number of our equipment operators and laborers are unionized. Any work stoppage or other labor dispute involving our unionized workforce, or inability to renew contracts with the unions, could have a material adverse effect on our operations and operating results.
 
Our contracts may require us to perform extra or change order work, which can result in disputes and adversely affect our working capital, profits and cash flows.
 
Our contracts often require us to perform extra or change order work as directed by the customer even if the customer has not agreed in advance on the scope or price of the extra work to be performed. This process may result in disputes over whether the work performed is beyond the scope of the work included in the original project plans and specifications or, if the customer agrees that the work performed qualifies as extra work, the price that the customer is willing to pay for the extra work. These disputes may not be settled to our satisfaction. Even when the customer agrees to pay for the extra work, we may be required to fund the cost of such work for a lengthy period of time until the change order is approved by the customer and we are paid by the customer.
 
To the extent that actual recoveries with respect to change orders or amounts subject to contract disputes or claims are less than the estimates used in our financial statements, the amount of any shortfall will reduce our future revenues and profits, and this could have a material adverse effect on our reported working capital and results of operations. In addition, any delay caused by the extra work may adversely impact the timely scheduling of other project work and our ability to meet specified contract milestone dates.
 
Our failure to meet schedule or performance requirements of our contracts could adversely affect us.
 
In most cases, our contracts require completion by a scheduled acceptance date. Failure to meet any such schedule could result in additional costs, penalties or liquidated damages being assessed against us, and these could exceed projected profit margins on the contract. Performance problems on existing and future contracts could cause actual results of operations to differ materially from those anticipated by us and could cause us to suffer damage to our reputation within the industry and among our customers.
 
The design-build project delivery method subjects us to the risk of design errors and omissions.
 
In the event of a design error or omission causing damages with respect to one of our design-build projects, we could be liable. Although we pass design responsibility on to the engineering firms that we engage to perform design services on our behalf for these projects, in the event of a design error or omission causing damages, there is risk that the engineering firm, its professional liability insurance, and the errors and omissions insurance that they and we purchase will not fully protect us from costs or liabilities. Any liabilities resulting from an asserted design defect with respect to our construction projects may have a material adverse effect on our financial position, results of operations and cash flows.
 
 
16

 
Adverse weather conditions may cause delays, which could slow completion of our contracts and negatively affect our revenues and cash flow.
 
Because all of our construction projects are built outdoors, work on our contracts is subject to unpredictable weather conditions, which could become more frequent or severe if general climatic changes occur. For example, evacuations in Texas due to hurricanes along the U.S. Gulf of Mexico coastal areas can result in our inability to perform work on all Houston-area contracts for several days. Lengthy periods of wet or cold winter weather will generally interrupt construction, and this can lead to under-utilization of crews and equipment, resulting in less efficient rates of overhead recovery. Extreme heat can prevent us from performing certain types of operations. During the late fall to the early spring months of each year, our work on construction projects in Nevada and Utah may also be curtailed because of snow and other work-limiting weather. While revenues can be recovered following a period of bad weather, it is generally impossible to recover the cost of inefficiencies, and significant periods of bad weather typically reduce profitability of affected contracts both in the current period and during the future life of affected contracts. Such reductions in contract profitability negatively affect our results of operations in current and future periods until the affected contracts are completed.
 
Timing of the award and performance of new contracts could have an adverse effect on our operating results and cash flow.
 
It is generally very difficult to predict whether and when new contracts will be offered for tender, as these contracts frequently involve a lengthy and complex design and bidding process, which is affected by a number of factors, such as market conditions, funding arrangements and governmental approvals. Because of these factors, our results of operations and cash flows may fluctuate from quarter to quarter and year to year, and the fluctuation may be substantial.
 
The uncertainty of the timing of contract awards may also present difficulties in matching the size of our equipment fleet and work crews with contract needs. In some cases, we may maintain and bear the cost of more equipment and ready work crews than are currently required, in anticipation of future needs for existing contracts or expected future contracts. If a contract is delayed or an expected contract award is not received, we would incur costs that could have a material adverse effect on our anticipated profit.
 
In addition, the timing of the revenues, earnings and cash flows from our contracts can be delayed by a number of factors, including adverse weather conditions, such as prolonged or intense periods of rain, snow, storms or flooding; delays in receiving material and equipment from suppliers and services from subcontractors; and changes in the scope of work to be performed. Such delays, if they occur, could have adverse effects on our operating results for current and future periods until the affected contracts are completed.
 
Our participation in construction joint ventures exposes us to liability and/or harm to our reputation for failures of our partners.
 
As part of our business, we are a party to joint venture arrangements, pursuant to which we typically jointly bid on and execute particular projects with other companies in the construction industry. Success on these joint projects depends upon managing the risks discussed in the various risks described in these “Risk Factors” and on whether our joint venture partners satisfy their contractual obligations.
 
We and our joint venture partners are generally jointly and severally liable for all liabilities and obligations of our joint ventures. If a joint venture partner fails to perform or is financially unable to bear its portion of required capital contributions or other obligations, including liabilities stemming from lawsuits, we could be required to make additional investments, provide additional services or pay more than our proportionate share of a liability to make up for our partner’s shortfall. Furthermore, if we are unable to adequately address our partner’s performance issues, the customer may terminate the project, which could result in legal liability to us, harm to our reputation and reduction to our profit on a project.
 
In connection with acquisitions, certain counterparties to joint venture arrangements, which may include our historical direct competitors, may not desire to continue such arrangements with us and may terminate the joint venture arrangements or not enter into new arrangements. Any termination of a joint venture arrangement could cause us to reduce our backlog and could materially and adversely affect our business, results of operations and financial condition.
 
Our dependence on a limited number of customers could adversely affect our business and results of operations.
 
 
17

 
Due to the size and nature of our construction contracts, one or a few customers have in the past and may in the future represent a substantial portion of our consolidated revenues and gross profits in any one year or over a period of several consecutive years. For example, in 2014, approximately 9.1% of our revenue was generated from North Texas Tollway Authority (“NTTA”) and approximately 14.5% was generated by Caltrans. Similarly, our backlog frequently reflects multiple contracts for certain customers; therefore, one customer may comprise a significant percentage of backlog at a certain point in time. Examples of this are TxDOT and Caltrans which comprised 30.6% and 23.2% of our backlog at December 31, 2014, respectively. The loss of business from any one of such customers could have a material adverse effect on our business or results of operations. Also, a default or delay in payment on a significant scale by a customer could materially adversely affect our business, results of operations, cash flows and financial condition.
 
We may incur higher costs to lease, acquire and maintain equipment necessary for our operations, and the market value of our owned equipment may decline.
 
A significant portion of our contracts is built with our own construction equipment rather than leased or rented equipment. To the extent that we are unable to buy construction equipment necessary for our needs, either due to a lack of available funding or equipment shortages in the marketplace, we may be forced to rent equipment on a short-term basis, which could increase the costs of performing our contracts.
 
The equipment that we own or lease requires continuous maintenance, for which we maintain our own repair facilities. If we are unable to continue to maintain the equipment in our fleet, we may be forced to obtain third-party repair services, which could increase our costs. In addition, the market value of our equipment may unexpectedly decline at a faster rate than anticipated.
 
An inability to obtain bonding could limit the aggregate dollar amount of contracts that we are able to pursue.
 
As is customary in the construction business, we are required to provide surety bonds to our customers to secure our performance under construction contracts. Our ability to obtain surety bonds primarily depends upon our capitalization, working capital, past performance, management expertise and reputation and certain external factors, including the overall capacity of the surety market. Surety companies consider such factors in relationship to the amount of our backlog and their underwriting standards, which may change from time to time. Events that adversely affect the insurance and bonding markets generally may result in bonding becoming more difficult to obtain in the future, or being available only at a significantly greater cost. Our inability to obtain adequate bonding would limit the amount that we can bid on new contracts and could have a material adverse effect on our future revenues and business prospects.
 
Our operations are subject to hazards that may cause personal injury or property damage, thereby subjecting us to liabilities and possible losses, which may not be covered by insurance.
 
Our workers are subject to the usual hazards associated with providing construction and related services on construction sites, plants and quarries. Operating hazards can cause personal injury and loss of life, damage to or destruction of property, plant and equipment and environmental damage. We maintain general liability and excess liability insurance, workers’ compensation insurance, auto insurance and other types of insurance all in amounts consistent with our risk of loss and industry practice, but this insurance may not be adequate to cover all losses or liabilities that we may incur in our operations.
 
Insurance liabilities are difficult to assess and quantify due to unknown factors, including the severity of an injury, the determination of our liability in proportion to other parties, the number of incidents not reported and the effectiveness of our safety program. If we were to experience insurance claims or costs above our estimates, we might be required to use working capital to satisfy these claims rather than to maintain or expand our operations. To the extent that we experience a material increase in the frequency or severity of accidents or workers’ compensation and health claims, or unfavorable developments on existing claims, our operating results and financial condition could be materially and adversely affected.
 
Environmental and other regulatory matters could adversely affect our ability to conduct our business and could require expenditures that could have a material adverse effect on our results of operations and financial condition.
 
 
18

 
Our operations are subject to various environmental laws and regulations relating to the management, disposal and remediation of hazardous substances, climate change and the emission and discharge of pollutants into the air and water. We could be held liable for such contamination created not only from our own activities but also from the historical activities of others on our project sites or on properties that we acquire or lease. Our operations are also subject to laws and regulations relating to workplace safety and worker health, which, among other things, regulate employee exposure to hazardous substances. Immigration laws require us to take certain steps intended to confirm the legal status of our immigrant labor force, but we may nonetheless unknowingly employ illegal immigrants. Violations of such laws and regulations could subject us to substantial fines and penalties, cleanup costs, third-party property damage or personal injury claims. In addition, these laws and regulations have become, and enforcement practices and compliance standards are becoming, increasingly stringent. Moreover, we cannot predict the nature, scope or effect of legislation or regulatory requirements that could be imposed, or how existing or future laws or regulations will be administered or interpreted, with respect to products or activities to which they have not been previously applied. Compliance with more stringent laws or regulations, as well as more vigorous enforcement policies of the regulatory agencies, could require us to make substantial expenditures for, among other things, pollution control systems and other equipment that we do not currently possess, or the acquisition or modification of permits applicable to our activities.
 
Our aggregate quarry lease in Nevada could subject us to costs and liabilities. As lessee and operator of the quarry, we could be held responsible for any contamination or regulatory violations resulting from activities or operations at the quarry. Any such costs and liabilities could be significant and could materially and adversely affect our business, operating results and financial condition.
 
Terrorist attacks have impacted, and could continue to negatively impact, the U.S. economy and the markets in which we operate.
 
Terrorist attacks, like those that occurred on September 11, 2001, have contributed to economic instability in the United States, and further acts of terrorism, violence or war could affect the markets in which we operate, our business and our expectations. Armed hostilities may increase, or terrorist attacks, or responses from the United States, may lead to further acts of terrorism and civil disturbances in the United States or elsewhere, which may further contribute to economic instability in the United States. These attacks or armed conflicts may affect our operations or those of our customers or suppliers and could impact our revenues, our production capability and our ability to complete contracts in a timely manner.
 
We rely on information technology systems to conduct our business, and disruption, failure or security breaches of these systems could adversely affect our business and results of operations.
 
We rely on information technology (“IT”) systems in order to achieve our business objectives. We also rely upon industry accepted security measures and technology to securely maintain confidential information maintained on our IT systems. However, our portfolio of hardware and software products, solutions and services and our enterprise IT systems may be vulnerable to damage or disruption caused by circumstances beyond our control such as catastrophic events, power outages, natural disasters, computer system or network failures, computer viruses, cyber-attacks or other malicious software programs. The failure or disruption of our IT systems to perform as anticipated for any reason could disrupt our business and result in decreased performance, significant remediation costs, transaction errors, loss of data, processing inefficiencies, downtime, litigation and the loss of suppliers or customers. A significant disruption or failure could have a material adverse effect on our business operations, financial performance and financial condition.
 
Risks Related to Our Financial Results and Financing Plans.
 
Actual results could differ from the estimates and assumptions that we use to prepare our financial statements.
 
To prepare financial statements in conformity with accounting principles generally accepted in the United States (“GAAP”), management is required to make estimates and assumptions, as of the date of the financial statements, which affect the reported values of assets and liabilities, revenues and expenses, and disclosures of contingent assets and liabilities. Areas requiring significant estimates by our management include: contract costs and profits; application of percentage-of-completion accounting and revenue recognition of contract change order claims; provisions for uncollectible receivables and customer claims and recoveries of costs from subcontractors, suppliers and others; impairment of long-term assets; valuation of assets acquired and liabilities assumed in connection with business combinations; accruals for estimated liabilities, including litigation and insurance reserves; and stock-based compensation. Our actual results could differ from, and could require adjustments to, those estimates.
 
In particular, as is more fully discussed in “Item 7. Management’s Discussion and Analysis of Financial Condition and Results of Operations — Critical Accounting Policies,” we recognize contract revenue using the percentage-of-completion method. Under this method, estimated contract revenue is recognized by applying the percentage of completion of the contract for the period (based on the ratio of costs incurred to total estimated costs of a contract) to the total estimated revenue for the contract. Estimated contract losses are recognized in full when determined. Contract revenue and total cost estimates are reviewed and revised on a continuous basis as the work progresses and as change orders are initiated or approved, and adjustments based upon the percentage of completion are reflected in contract revenue in the accounting period when these estimates are revised. To the extent that these adjustments result in an increase, a reduction or an elimination of previously reported contract profit, we recognize a credit or a charge against current earnings, which could be material.
 
 
19

 
We may need to raise additional capital in the future for working capital, capital expenditures and/or acquisitions, and we may not be able to do so on favorable terms or at all, which would impair our ability to operate our business or achieve our growth objectives.
 
Our ability to obtain additional financing in the future will depend in part upon prevailing credit and equity market conditions, as well as conditions in our business and our operating results; such factors may adversely affect our efforts to arrange additional financing on terms satisfactory to us. We have pledged the proceeds and other rights under our construction contracts to our bond surety, and we have pledged substantially all of our other assets as collateral in connection with our credit facility and mortgage debt. As a result, we may have difficulty in obtaining additional financing in the future if such financing requires us to pledge assets as collateral. In addition, under our credit facility, we must obtain the consent of our lenders to incur any amount of additional debt from other sources (subject to certain exceptions). If future financing is obtained by the issuance of additional shares of common stock, our stockholders may suffer dilution. If adequate funds are not available, or are not available on acceptable terms, we may not be able to make future investments, take advantage of acquisitions or other opportunities, or respond to competitive challenges.
 
We are subject to financial and other covenants under our credit facility that could limit our flexibility in managing our business.
 
We have a credit facility that restricts us from engaging in certain activities, including our ability (subject to certain exceptions) to:
 
·
make distributions, pay dividends and buy back shares;
·
incur liens or encumbrances;
·
incur other indebtedness;
·
guarantee obligations;
·
dispose of a material portion of assets;
·
engage in a merger with a third party; and
·
make acquisitions.
 
Our credit facility contains financial covenants that require us to maintain specified asset ratios and leverage ratios, and to maintain specified levels of tangible net worth. Our ability to borrow funds for any purpose will depend on our satisfying these tests. If we are unable to meet the terms of the financial covenants or fail to comply with any of the other restrictions contained in our credit facility, an event of default could occur. An event of default, if not waived by our lenders, could result in the acceleration of any outstanding indebtedness, causing such debt to become immediately due and payable. If such acceleration occurs, we may not be able to repay such indebtedness on a timely basis. Acceleration of our credit facility could result in foreclosure on and loss of our operating assets. In the event of such foreclosure, we would be unable to conduct our business and forced to discontinue operations.
 
We must manage our liquidity carefully to fund our working capital.
 
The need for working capital for our business varies due to fluctuations in the following amounts, among other factors:
 
·
contract receivables and contract retentions;
·
costs and estimated earnings in excess of billings;
·
billings in excess of costs and estimated earnings;
·
the size and status of contract mobilization payments and progress billings; and
·
the amounts owed to suppliers and subcontractors.
 
We have limited cash on hand and the timing of payments on our contract receivables are difficult to predict. If the timing of payments on our receivables is delayed or the amount of such payments is less than expected, our liquidity and ability to fund working capital could be materially and adversely affected.
 
If we were required to write down all or part of our goodwill, our net earnings and net worth could be materially and adversely affected.
 
We had $54.8 million of goodwill recorded on our consolidated balance sheet at December 31, 2014. Goodwill represents the excess of cost over the fair value of net assets acquired in business combinations reduced by any impairments recorded subsequent to the date of acquisition. A shortfall in our revenues or net income or changes in various other factors from that expected by securities analysts and investors could significantly reduce the market price of our common stock. If our market capitalization drops significantly below the amount of net equity recorded on our balance sheet, it might indicate a decline in our fair value and would require us to further evaluate whether our goodwill has been impaired. We perform an annual test of our goodwill to determine if it has become impaired. On an interim basis, we also review the factors that have or may affect our operations or market capitalization for events that may trigger impairment testing. Write downs of goodwill may be substantial. For example, in 2011, our annual test indicated that goodwill was impaired, and as a result we recorded a charge of $67.0 million representing approximately 55% of the $121 million of recorded goodwill prior to the write down. As a result, the Company incurred a significant loss for 2011 and equity declined by $41.8 million. If we were required to write down all or a significant part of our goodwill in future periods our net earnings and equity could be materially and adversely affected.
 
 
20

 
Item 1B. Unresolved Staff Comments
 
None
 
Item 2. Properties
 
Our corporate headquarters are located in The Woodlands, Texas, in 12,340 square feet of office space leased with an eight year term. Our executive, finance and accounting offices are located at this facility. We also have an office located in Lafayette, Colorado where we lease a small office for our information technology professionals.
 
Our TSC office building is located in Houston, Texas, which houses TSC’s executive management, project management and finance and accounting offices. The building is located on a seven-acre parcel of land on which the TSC Houston division’s equipment repair center is also located. We also own land, have repair facilities and have constructed offices in San Antonio and Dallas.
 
Our Utah operations leases office space in Draper, Utah, near Salt Lake City, and also repair facilities in West Jordan City, Utah from entities owned primarily by certain officers of RLW. Refer to Note 19 to the consolidated financial statements for additional information regarding related party transactions.
 
Our Nevada operations leases office space in Sparks, Nevada, and we own our office and repair facilities located on a forty-five acre parcel of land in Lovelock, Nevada. We also lease the right to mine stone and sand at four quarry sites in Nevada. In Nevada, we generally source and produce our own aggregates, either from our own quarries or from other sources near job sites where we enter into short-term leases to acquire the aggregates necessary for the job.
 
Our Arizona, California and Hawaii operations lease office space in Tempe, Sacramento and Honolulu, respectively.
 
In order to complete most contracts, we also lease small parcels of real estate near the site of a contract job site to store materials, locate equipment, and provide offices for the contracting customer, its representatives and our employees.
 
Item 3. Legal Proceedings.
 
We are and may in the future be involved as a party to various legal proceedings that are incidental to the ordinary course of business. We regularly analyze current information about these proceedings and, as necessary, provide accruals for probable liabilities on the eventual disposition of these matters.
 
In the opinion of management, after consultation with legal counsel, there are currently no threatened or pending legal matters that would reasonably be expected in the future to have a material adverse impact on our consolidated results of operations, financial position or cash flows.
 
Item 4. Mine Safety Disclosures.
 
The information concerning mine safety violations and other regulatory matters required by section 1503(a) of the Dodd-Frank Wall Street Reform and Consumer Protection Act and Item 104 of Regulation S-K is included in Exhibit 95.1 of this Annual Report on Form 10-K, which is incorporated by reference.
 
Executive Officers of the Registrant
(At March 1, 2015)
 
The following is a list of the Company's three executive officers, their ages, positions, offices and the year they became executive officers together with a brief description of their business experience.
 
Name
Age
Position/Offices
Executive
Officer Since
Paul J. Varello
71
Chairman of the Board of Directors, Chief Executive Officer
2015
Thomas R. Wright
51
Executive Vice President & Chief Financial Officer, Treasurer
2013
Roger M. Barzun
73
Senior Vice President & General Counsel, Secretary
2006
 
Each executive officer is elected by the Board of Directors and, subject to the terms of any employment agreement he may have with the Company, holds office for such term as the Board of Directors may prescribe, or until his death, disqualification, resignation or removal.
 
 
21

 
 
Mr. Varello, who has been a director of the Company since January 2014, and Chairman of the Board of Directors since December 2014, was elected acting Chief Executive Officer after the Company's former President & Chief Executive Officer, Peter E. MacKenna, left the Company on January 31, 2015. Mr. Varello is the Founder and President of Commonwealth Projects, LLC, a project development company specializing in developing LNG projects in the Caribbean Basin and Bermuda. He is the former Founder and Chairman of Commonwealth Engineering & Construction, LLC (CEC) an engineering and construction management company specializing in the design and construction of major capital projects for the oil & gas, refining, alternative fuels, power, and related energy industries, which he sold in 2014. Prior to founding CEC in May 2003, Mr. Varello was Senior Partner of Varello & Associates, a company that provided technical assessments, economic evaluations, estimates and constructability reviews to project lenders, plant operators and engineering companies from September 2001 to May 2003. From May 1990 to September 2001, Mr. Varello was Chairman of the Board and Chief Executive Officer of American Ref-Fuel Company of Houston, Texas. The company was formed as a joint venture of two publicly-traded companies to develop, own and operate plants that convert solid municipal waste into energy. For the eighteen years prior to 1990, Mr. Varello was with Fluor Corporation, a Fortune 500 company that provides engineering, procurement, construction, maintenance, and project management services to a wide range of global clients. Mr. Varello started with Fluor as a project construction manager and rose to President of the Process Sector. Mr. Varello is a Registered Professional Engineer in California, Texas and Louisiana, and holds a Bachelor of Civil Engineering from Villanova University. He is also a graduate of Harvard Business School's Advanced Management Program.
 
Mr. Wright was elected Executive Vice President & Chief Financial Officer and Treasurer effective September 25, 2013. From February 2011 until he joined the Company, Mr. Wright was Chief Financial Officer of Toronto-based St Mary's/CBM, a leading North American cement and concrete company. Prior to that, from April 2006 to September 2010, he was with Boart Longyear Company, a global drilling services and products manufacturing company, initially as Vice President, Finance, Global Products and Manufacturing, and subsequently as Vice President, Financial Planning and Analysis, Mergers and Acquisitions, Investor Relations, Strategic Planning, and Corporate Communications. Mr. Wright holds an MBA in Finance from the Indiana University.
 
Mr. Barzun has been an officer of the Company for more than the last five years and also serves as general counsel to other companies from time to time on a part-time basis. He is a member of the bar of New York and Massachusetts.
 
 
22

 
PART II
 
Item 5. Market for the Registrant’s Common Equity, Related Stockholder Matters and Issuer Purchases of Equity Securities.
 
The Company’s common stock is traded on the NASDAQ Global Select Market (“NGS”). The table below shows the market high and low closing sales prices of the common stock for 2013 and 2014 by quarter.
 
   
High
   
Low
 
Year Ended December 31, 2013
           
First Quarter
  $ 11.78     $ 9.80  
Second Quarter
    10.97       8.91  
Third Quarter
    10.50       9.13  
Fourth Quarter
    12.17       8.67  
Year Ended December 31, 2014
               
First Quarter
  $ 11.63     $ 8.67  
Second Quarter
    9.60       6.78  
Third Quarter
    9.88       7.46  
Fourth Quarter
    9.15       5.67  
 
On February 28, 2015, there were 930 holders of record of our common stock.
 
Dividend Policy.
 
We have never paid any cash dividends on our common stock. For the foreseeable future, we intend to retain any earnings in our business, and we do not anticipate paying any cash dividends. Whether or not we declare any dividends will be at the discretion of the Board of Directors considering then-existing conditions, including the Company’s financial condition and results of operations, capital requirements, bonding prospects, contractual restrictions (including those under the Company’s “Credit Facility” – the credit facility entered into October 31, 2007 with Comerica Bank), business prospects and other factors that our Board of Directors considers relevant.
 
Equity Compensation Plan Information.
 
Certain information about the Company's equity compensation plans is incorporated into Item 12. — Security Ownership of Certain Beneficial Owners and Management and Related Stockholder Matters from the Company's proxy statement for its 2015 Annual Meeting of Stockholders.
 
Performance Graph.
 
The following graph compares the percentage change in the Company’s cumulative total stockholder return on its common stock for the last five years with the Dow Jones US Total Return Index, a broad market index, and the Dow Jones US Heavy Construction Index, a group of companies whose marketing strategy is focused on a limited product line, such as civil construction. Both indices are published in The Wall Street Journal.
 
The returns are calculated assuming that an investment with a value of $100 was made in the Company’s common stock and in each index at the end of 2009 and that all dividends were reinvested in additional shares of common stock; however, the Company has paid no dividends during the periods shown. The graph lines merely connect the measuring dates and do not reflect fluctuations between those dates. The stock performance shown on the graph is not intended to be indicative of future stock performance.
 
 
23

 
 
 
 
   
December
2009
($)
   
December
2010
($)
   
December
2011
($)
   
December
2012
($)
   
December
2013
($)
   
December
2014
($)
 
Sterling Construction Company, Inc.
    100.00       68.13       56.27       51.93       61.29       33.39  
Dow Jones US Total Return Index
    100.00       116.65       118.22       137.52       182.86       206.53  
Dow Jones US Heavy Construction Index
    100.00       128.40       105.86       128.54       168.74       125.68  
 
Issuer Purchases of Equity Securities.
 
In October 2008, the Company announced a share-repurchase program to purchase up to $5 million in shares of common stock. In August 2010, the Company announced an increase to the share-repurchase program to purchase an additional $5 million in shares of common stock, for a total up to $10 million. The specific timing and amount of repurchase will vary based on market conditions, securities law limitations and other factors. There were no repurchases of shares during the three months ended December 31, 2014.
 
 
24

 
Item 6. Selected Financial Data
 
The following table sets forth selected financial and other data of the Company and its subsidiaries and should be read in conjunction with both “Item 7. Management’s Discussion and Analysis of Financial Condition and Results of Operations,” which follows, and “Item 8. Financial Statements and Supplementary Data.” Amounts are in thousands, except per share data:
 
   
Years ended December 31,
 
   
2014
   
2013
   
2012
   
2011
   
2010
 
Revenues
  $ 672,230     $ 556,236     $ 630,507     $ 501,156     $ 459,893  
(Loss) Income before income taxes and earnings attributable to noncontrolling interests
  $ (4,593 )   $ (68,804 )   $ 17,133     $ (51,716 )   $ 36,494  
Income tax (expense) benefit
    (632 )     (1,222 )     579       17,012       (10,270 )
Net (loss) income
    (5,225 )     (70,026 )     17,712       (34,704 )     26,224  
Noncontrolling owners’ interests in earnings of subsidiaries
    (4,556 )     (3,903 )     (18,009 )     (1,196 )     (7,137 )
Net income (loss) attributable to Sterling common stockholders
  $ (9,781 )   $ (73,929 )   $ (297 )   $ (35,900 )   $ 19,087  
                                         
Net income (loss) per share attributable to Sterling common stockholders:
                                       
Basic
  $ (0.54 )   $ (4.91 )   $ (0.26 )   $ (2.24 )   $ 1.15  
Diluted
  $ (0.54 )   $ (4.91 )   $ (0.26 )   $ (2.24 )   $ 1.13  
                                         
Weighted average number of common shares outstanding used in computing per share amounts:
                                       
Basic
    18,063       16,635       16,421       16,396       16,195  
Diluted
    18,063       16,635       16,421       16,396       16,563  
Cash dividends declared
  $ --     $ --     $ --     $ --     $ --  
Balance sheet:
                                       
Total assets
  $ 306,451     $ 273,018     $ 331,510     $ 303,831     $ 367,131  
Long-term debt
  $ 37,021     $ 8,331     $ 24,201     $ 263     $ 336  
Equity attributable to Sterling common stockholders
  $ 133,686     $ 128,893     $ 210,148     $ 213,311     $ 250,429  
Book value per share of outstanding common stock attributable to Sterling common stockholders
  $ 7.11     $ 7.74     $ 12.74     $ 13.07     $ 15.21  
Shares outstanding
    18,803       16,658       16,495       16,321       16,468  
 
 
25

 
Item 7. Management’s Discussion and Analysis of Financial Condition and Results of Operations.
 
Overview.
 
We are a company that operates in one segment, heavy civil construction, through our subsidiaries, and which specializes in the building, reconstruction and repair of transportation and water infrastructure in Texas, Utah, Nevada, Arizona, California, Hawaii and other states where we see opportunities.  We have strategically expanded our operations, either by establishing an office in a new market, often after having successfully bid on and completed a project in that market, or by acquiring a company that gives us an immediate entry into a market.
 
Critical Accounting Policies.
 
On an ongoing basis, the Company evaluates the critical accounting policies used to prepare its consolidated financial statements, including, but not limited to, those related to:
 
·
Revenue recognition
 
·
Contracts receivable, including retainage
 
·
Valuation of long-lived assets and goodwill
 
·
Income taxes
 
·
Segment reporting
 
Our significant accounting policies are described in Note 1 to the consolidated financial statements, and conform to the Financial Accounting Standards Board’s Accounting Standards Codification (or GAAP or ASC).
 
Use of Estimates.
 
The preparation of financial statements in conformity with GAAP requires management to make estimates and assumptions that affect the reported amounts of assets and liabilities, the disclosure of contingent assets and liabilities at the date of the financial statements, and the reported amounts of revenues and expenses during the reporting period. Certain of the Company’s accounting policies require higher degrees of judgment than others in their application. These include the recognition of revenue and earnings from construction contracts under the percentage-of-completion method, the valuation of long-lived assets, and income taxes. Management continually evaluates all of its estimates and judgments based on available information and experience; however, actual amounts could differ from those estimates.
 
Revenue Recognition.
 
The majority of our construction contracts with our customers are “fixed unit price.” Under such contracts, we are committed to providing materials or services required by a contract at fixed unit prices (for example, dollars per cubic yard of concrete poured or per cubic yard of earth excavated). Most of our state and municipal contracts provide for termination of the contract for the convenience of the owner, with provisions to pay us only for work performed through the date of termination.
 
Revenue from these construction contracts is recognized using the percentage-of-completion accounting method. Under this method, revenue is recognized as costs are incurred in an amount equal to cost plus the related expected profit based on the ratio of costs incurred to estimated final costs. This cost to cost measure is used because management considers it to be the best available measure of progress on these contracts. Contract costs consist of direct costs on contracts, including labor, materials, amounts payable to subcontractors and those indirect costs related to contract performance, such as indirect salaries and wages, equipment maintenance, repairs, fuel and depreciation, insurance and payroll taxes. Contract cost is recorded as incurred, and revisions in contract revenue and cost estimates are reflected in the accounting period when known.  Provisions for estimated losses on uncompleted contracts are made in the period in which such losses are determined. Changes in job performance, job conditions and estimated profitability, including those changes arising from contract change orders, penalty provisions and final contract settlements may result in revisions to costs and income and are recognized in the period in which the revisions are determined.
 
Change orders are modifications of an original contract that effectively change the existing provisions of the contract without adding new scope or terms. Change orders may include changes in specifications or designs, manner of performance, facilities, equipment, materials, sites and period of completion of the work. Either we or our customers may initiate change orders.
 
 
26

 
The Company considers unapproved change orders to be contract variations for which we have customer approval for a change of scope but a price change associated with the scope change has not yet been agreed upon. Costs associated with unapproved change orders are included in the estimated cost to complete the contracts and are treated as project costs as incurred. The Company recognizes revenue equal to costs incurred on unapproved change orders when realization of price approval is probable. Unapproved change orders involve the use of estimates, and it is reasonably possible that revisions to the estimated costs and recoverable amounts may be required in future reporting periods to reflect changes in estimates or final agreements with customers. Change orders that are unapproved as to both price and scope are evaluated as claims.
 
The Company considers claims to be amounts in excess of agreed contract prices that we seek to collect from our customers or others for customer-caused delays, errors in specifications and designs, contract terminations, change orders that are either in dispute or are unapproved as to both scope and price, or other causes of unanticipated additional contract costs.  Revenue from claims is recognized when an agreement is reached with customers as to the value of the claims, which in some instances may not occur until after completion of work under the contract. Costs associated with claims are included in the estimated costs to complete the contracts and are treated as project costs when incurred.
 
Our contracts generally take 12 to 36 months to complete. The Company generally provides a one to two-year warranty for workmanship under its contracts when completed.  Warranty claims historically have been insignificant.
 
The accuracy of our revenue and profit recognition in a given period is dependent on the accuracy of our estimates of the revenues and costs to finish uncompleted contracts. Our estimates for all of our significant contracts use a highly detailed “bottom up” approach, and we believe our experience allows us to produce reliable estimates. However, our projects can be highly complex, and in almost every case, the profit margin estimates for a contract will either increase or decrease to some extent from the amount that was originally estimated at the time of bid. Because we have a large number of projects of varying levels of size and complexity in process at any given time, these changes in estimates can sometimes offset each other without materially impacting our overall profitability. However, large changes in revenue or cost estimates can have a significant effect on profitability. There are a number of factors that can contribute to changes in estimates of contract cost and profitability. The most significant of these include the completeness and accuracy of the original bid, recognition of costs associated with scope changes, extended overhead due to customer-related and weather-related delays, subcontractor and supplier performance issues, site conditions that differ from those assumed in the original bid (to the extent contract remedies are unavailable), the availability and skill level of workers in the geographic location of the project and changes in the availability and proximity of materials. The foregoing factors, as well as the stage of completion of contracts in process and the mix of contracts at different margins, may cause fluctuations in gross profit between periods, and these fluctuations may be significant.  Results for 2014, 2013 and 2012 were adversely affected by revisions to estimated profitability on a number of construction projects. See “Recent Developments ― Financial Results for 2014, Operational Issues and Outlook for 2015 Financial Results” above and “Results of Operations ― Fiscal Year Ended December 31, 2014 Compared with Fiscal Year Ended December 31, 2013” for further discussion of the impact on our financial results.
 
Contracts Receivable, Including Retainage.
 
Contracts receivable are generally based on amounts billed to the customer. At December 31, 2014 and 2013, contracts receivable included $16.4 million and $18.3 million of retainage, respectively, which is being withheld by customers until completion of the contracts. All other contracts receivable include only balances approved for payment by the customer.
 
Many of the contracts under which the Company performs work contain retainage provisions. Retainage refers to that portion of billings made by the Company but held for payment by the customer pending satisfactory completion of the project. Retainage on active contracts is classified as a current asset regardless of the term of the contract and is generally collected within one year of the completion of a contract.
 
There are certain contracts that are completed in advance of full payment. When the receivable will not be collected within our normal operating cycle, we consider it a long-term contract receivable and it is recorded in “Other assets, net” in our balance sheet.  At December 2014 and 2013, there was $5.0 million and $7.8 million recorded, respectively.  We consider the credit quality of the borrower to assess the appropriate discount rate to apply and continuously monitor the borrower’s credit quality.
 
As the majority of our construction contracts are entered into with state or municipal government customers, credit risk is minimal. The Company ascertains that funds have been appropriated by the governmental project owner prior to commencing work on such projects. While most public contracts are subject to termination at the election of the government entity, in the event of termination the Company is entitled to receive the contract price for completed work and reimbursement of termination-related costs. Credit risk with private owners is minimized because of statutory mechanics liens, which give the Company high priority in the event of lien foreclosures following financial difficulties of private owners.
 
Contracts receivable are written off based on individual credit evaluation and specific circumstances of the customer, when such treatment is warranted. There was no bad debt expense recorded in 2014 or in 2012. In 2013, the Company wrote off $1.8 million of contracts receivable to bad debt expense which was recorded in “Other operating income, net.” During 2014, we recovered $1.0 million of this $1.8 million.
 
 
27

 
Based upon a review of outstanding contracts receivable, historical collection information and existing economic conditions, management has determined that all contracts receivable at December 31, 2014 are fully collectible, and accordingly, no allowance for doubtful accounts against contracts receivable is necessary.
 
Valuation of Long-Lived Assets and Goodwill.
 
Long-lived assets, which include property, equipment and acquired intangible assets, including goodwill, are reviewed for impairment whenever events or changes in circumstances indicate that the carrying amount of an asset may not be recoverable. Impairment evaluations involve fair values and management estimates of useful asset lives and future cash flows. Actual useful lives and cash flows could be different from those estimated by management, and this could have a material effect on operating results and financial position. For the years ended December 31, 2014 and 2013, there were no events or changes in circumstances that would indicate an impairment of our long-lived assets.
 
Goodwill must be tested for impairment at least annually, and we performed our most recent annual impairment test of historical goodwill on October 1, 2014.  Based on our one reporting unit, our test indicated there was no impairment of goodwill.  See “Segment Reporting” below for further information regarding the determination of our reporting unit. Note 8 to the consolidated financial statements discusses the two valuation approaches used by the Company to determine the fair value of the Company’s equity for purposes of evaluating whether there is an indication of goodwill impairment.  These valuation approaches are impacted by a number of factors but the key factors are the Company’s stock price, the estimated control premium and the estimated forecasted cash flows.  The valuation approaches contain uncertainty regarding the estimates used. One of the largest uncertainties relates to local, state and government spending which management expects to increase in the upcoming years. There are a number of other uncertainties with respect to our future financial performance that could impact estimated future cash flows. These are discussed in a number of places including “Item 1A. Risk Factors.” We determined that the fair value of the Company’s equity was approximately 19% above the carrying value of the Company’s equity.
 
After the annual test was completed, the Company’s stock price decreased from $7.54 on October 1, 2014 to $6.39 on December 31, 2014. Due to the decrease in the stock price, we noted that a goodwill impairment triggering event occurred during the fourth quarter of 2014. Therefore, we updated our annual goodwill impairment assessment using the two methods discussed in Note 8. The methods now included fourth quarter information which incorporated the Company’s stock price at December 31, 2014 and reduced gross margins used in our discounted cash flow model projections. Based on this revised testing, there was no goodwill impairment and we determined that the fair value of the Company’s equity was approximately 13% above the carrying value of the Company’s equity.
 
On January 27, 2015, we announced our preliminary fourth quarter and full year 2014 results and that we were not in compliance with our Credit Facility’s tangible net worth covenant as of December 31, 2014.
 
We believe these announcements negatively impacted the Company’s stock price which decreased from $5.52 on January 26, 2015 to $3.97 on January 27, 2015, and has not yet recovered. Due to the decrease in the stock price, we noted that a goodwill impairment triggering event may have occurred in January 2015. We believe an impairment is possible if our stock price does not recover. At this time, we believe that our stock price is undervalued as a result of these announcements and will ultimately recover. However, a modest change in estimated forecasted cash flows, a continued depressed stock price, or declines in other key factors discussed above, could result in an impairment of goodwill. At December 31, 2014, we had goodwill with a remaining carrying amount of approximately $54.8 million.
  
Income Taxes.
 
Deferred tax assets and liabilities are recognized based on the differences between the financial statement carrying amounts and the tax bases of assets and liabilities. We regularly review our deferred tax assets for recoverability and, where necessary, establish a valuation allowance.
 
Valuation allowances are established to reduce deferred tax assets if we determine that it is more likely than not (e.g., a likelihood of more than 50%) that some or all of the deferred tax assets will not be realized in future periods. To assess the likelihood, we use estimates and judgment regarding our future taxable income, as well as the jurisdiction in which this taxable income is generated, to determine whether a valuation allowance is required. Such evidence can include our current financial position, our results of operations, both actual and forecasted results, the reversal of deferred tax liabilities, and tax planning strategies as well as the current and forecasted business economics of our industry. Additionally, we record uncertain tax positions at their net recognizable amount, based on the amount that management deems is more likely than not to be sustained upon ultimate settlement with the tax authorities in the domestic and international tax jurisdictions in which we operate. On the basis of our evaluations, at December 31, 2014 and 2013, a valuation allowance was recorded on our net deferred tax assets and we had no material uncertain tax positions.
 
 
28

 
If our estimates or assumptions regarding our current and deferred tax items are inaccurate or are modified, these changes could have potentially material impacts on our earnings.
 
Segment Reporting.
 
We operate in one segment and have only one reportable segment and one reporting unit component, which is heavy civil construction. In making this determination, the Company considered the discrete financial information used by our Chief Operating Decision Maker (“CODM”). Based on this approach, the Company noted that the CODM organizes, evaluates and manages the financial information around each heavy civil construction project when making operating decisions and assessing the Company’s overall performance. The service provided by the Company, in all instances of our construction projects, is heavy civil construction. Furthermore, we considered that each heavy civil construction project has similar characteristics, includes similar services, has similar types of customers and is subject to similar economic and regulatory environments which would allow aggregation of individual operating segments into one reportable segment if multiple operating segments existed.
 
In addition, the Company noted that even if our local offices were to be considered separate components of our heavy civil construction operating segment, those components could be aggregated into a single reporting unit for purposes of testing goodwill for impairment because our local offices all have similar economic characteristics and are similar in all of the following areas:
 
·
The nature of the products and services — each of our local offices perform similar construction projects — they build, reconstruct and repair roads, highways, bridges, light rail and water, waste water and storm drainage systems.
·
The nature of the production processes — our heavy civil construction services rendered in the construction process for each of our construction projects performed by each local office is the same — they excavate dirt, remove existing pavement and pipe, lay aggregate or concrete pavement, pipe and rail and build bridges and similar large structures in order to complete our projects.
·
The type or class of customer for products and services — substantially all of our customers are state departments of transportation, cities, counties, and regional water, rail and toll-road authorities. A substantial portion of the funding for the state departments of transportation to finance the projects we construct is furnished by the federal government.
·
The methods used to distribute products or provide services — the heavy civil construction services rendered on our projects are performed primarily with our own field work crews (laborers, equipment operators and supervisors) and equipment (backhoes, loaders, dozers, graders, cranes, pug mills, crushers, and concrete and asphalt plants).
·
The nature of the regulatory environment — we perform substantially all of our projects for federal, state and municipal governmental agencies, and all of the projects that we perform are subject to substantially similar regulation under U.S. and state department of transportation rules, including prevailing wage and hour laws; codes established by the federal government and municipalities regarding water and waste water systems installation; and laws and regulations relating to workplace safety and worker health of the U.S. Occupational Safety and Health Administration and to the employment of immigrants of the U.S. Department of Homeland Security.
 
While profit margin objectives included in contract bids have some variability from contract to contract, our profit margin objectives are not differentiated by our CODM or our office management based on local office location. Instead, the projects undertaken by each local office are primarily competitively-bid, fixed unit or negotiated lump sum price contracts, all of which are bid based on achieving gross margin objectives that reflect the relevant skills required, the contract size and duration, the availability of our personnel and equipment, the makeup and level of our existing backlog, our competitive advantages and disadvantages, prior experience, the contracting agency or customer, the source of contract funding, anticipated start and completion dates, construction risks, penalties or incentives and general economic conditions.
 
Results of Operations.
 
Backlog at December 31, 2014
 
At December 31, 2014, our backlog of construction projects was $764 million, as compared to $687 million at December 31, 2013. Our contracts are typically completed in 12 to 36 months.  At December 31, 2014, there was approximately $24 million excluded from our consolidated backlog where we were the apparent low bidder, but had not yet been formally awarded the contract or the contract price had not been finalized.  Backlog includes $16 million attributable to our share of estimated revenues related to joint ventures where we are a noncontrolling joint venture partner.  As discussed further in “Item 1. Business―Recent Developments―Financial Results for 2014, Operational Issues and Outlook for 2015 Financial Results,” our backlog reflects, in part, our recently implemented strategy to target smaller, shorter duration projects with a particular focus on improved gross margins.
 
We expect that our markets will ultimately recover from the conditions discussed in “Item 1. Business.” Furthermore, we believe that the Company is well-established in our particular markets and has a fleet of modern equipment that gives us the ability to perform a broad range of work which will allow us to weather current market conditions and continue to compete successfully for projects as they become available at acceptable profit margin levels. See “Item 1. Business — Our Markets, Customers and Competition” for a more detailed discussion of our markets and their funding sources.
 
 
29

 
Fiscal Year Ended December 31, 2014 Compared with Fiscal Year Ended December 31, 2013
 
   
2014
   
2013
   
% Change
 
   
(Dollar amounts in thousands)
       
Revenues
  $ 672,230     $ 556,236       20.9 %
Gross profit (loss)
  $ 32,421     $ (29,944 )  
NM
 
General and administrative expenses
    (36,897 )     (40,951 )     (9.9 )
Other income
    252       1,737       (85.5 )
Operating loss
    (4,224 )     (69,158 )     (93.9 )
Gains on sale of securities
    --       91    
NM
 
Interest income
    754       879       (14.2 )
Interest expense
    (1,123 )     (616 )     82.3  
Loss before income taxes and earnings attributable to noncontrolling interests
    (4,593 )     (68,804 )     (93.3 )
Income tax expense
    (632 )     (1,222 )     (48.3 )
Net loss
    (5,225 )     (70,026 )     (92.5 )
Noncontrolling owners’ interests in earnings of subsidiaries and joint ventures
    (4,556 )     (3,903 )     16.7  
Net loss attributable to Sterling common stockholders
  $ (9,781 )   $ (73,929 )     (86.8 )
Gross margin (deficit)
    4.8 %     (5.4 )%  
NM
 
Operating margin (deficit)
    (0.6 )%     (12.5 )%     (95.2 )
Contract backlog, end of year
  $ 764,000     $ 687,000       11.2  
 
NM – Not meaningful.
 
Revenues.
 
Revenues for 2014 increased 20.9% compared with the prior year. This increase is primarily attributable to an increase in the number of projects in progress, largely in our Texas and California markets. However, this increase in revenue was weaker than we anticipated, primarily in our California, Utah and Hawaii markets. The 2013 revenues were adversely affected by the completion of large projects in Utah and to a lesser extent the completion of significant projects in Arizona.
 
Gross Profit.
 
Gross profit increased $62.4 million in 2014 compared with the prior year. Gross margin also increased to 4.8% in 2014 from (5.4)% in 2013 primarily due to net downward revisions of estimated revenues and gross margins on construction projects in Texas and Arizona in the prior year. In 2014, timing and weather issues impacted some large projects in our Hawaii and California operations, while spot shortages of commodities, over-stretched sub-contractors and vendors, and intense competition for craft labor continued to pressure our Texas operations which led to a less than anticipated gross profit.
 
While there are a number of factors which cause the costs incurred and gross profit realized on our contracts to vary, sometimes substantially, from our original projections, the primary factors which resulted in downward revisions in estimates in 2014 were:
 
·
conditions or contract requirements that differed from those assumed in the original bid or contract;
·
delays in taking measures to address issues which arose during construction;
·
subcontractors performance issues and vendor material spot shortages which caused project progress delays; and
·
shortage of skilled labor, particularly in our Texas market.
 
We may be entitled to claim proceeds related to customer-caused delays, errors in specification and designs or other causes of unanticipated additional costs related to certain projects; however, we cannot predict the amount of claim proceeds or the timing of the receipt of such proceeds.  Claims are recognized in revenue when an agreement is reached with the customer as to the value of the claims, which in some instances may not occur until after completion of work under the contract.
 
 
30

 
At December 31, 2014, we had approximately 116 contracts-in-progress which were less than 90% complete of various sizes, of different expected profitability and in various stages of completion.  The nearer a contract progresses toward completion, the more visibility we have in refining our estimate of total revenues (including incentives, delay penalties and change orders), costs and gross profit.  Thus gross profit as a percent of revenues can increase or decrease from comparable and sequential quarters due to variations among contracts and depending upon the stage of completion of contracts.
 
General and administrative expenses.
 
General and administrative expenses decreased $4.1 million during 2014 to $36.9 million from $41.0 million in 2013. This decrease is due to certain non-recurring costs in 2013 related to employee benefit costs, as well as costs associated with the evaluation and pursuit of potential acquisition opportunities.
 
As a percentage of revenues, general and administrative expenses decreased to 5.5% in 2014 from 7.4% in 2013. The decrease in the 2014 percentage as compared to 2013 percentage is the result of the decrease in expenses mentioned above and the result of investments made in 2013 in our information systems infrastructure and operational and financial process improvements which allowed us to increase our efficiency without a significant increase in general and administrative expenses.
 
Income taxes.
 
Our effective income tax rates for 2014 and 2013 were (13.8)% and (1.8)%, respectively. In 2014 and in 2013, our effective income tax rate varied from the statutory rate primarily as a result of our deferred tax asset valuation allowance.
 
In order to determine that a valuation allowance was necessary, management assessed the available positive and negative evidence to estimate whether sufficient future taxable income would be generated to use the existing deferred tax assets. A significant piece of objective negative evidence evaluated was the cumulative loss incurred over the three-year period ended December 31, 2014. The cumulative three-year period loss that ended in the fourth quarter of 2014 was the result of the write-downs recorded during 2013 and 2014. Such objective evidence limits the ability to consider other subjective evidence such as our projections for future growth. On the basis of this evaluation, as of December 31, 2014, a valuation allowance of $36.6 million has been recorded on our net deferred tax assets including federal and state net operating losses as they are not likely to be realized. The amount of the deferred tax asset considered realizable could be adjusted if objective negative evidence is no longer present and additional weight may be given to subjective evidence such as our projections for growth.
 
Net income attributable to noncontrolling interests.
 
The increase of $0.7 million to $4.6 million from $3.9 million in net income attributable to noncontrolling interest owners for the year ended December 31, 2014 compared with same period in 2013 is primarily related to net income attributable to the 50% noncontrolling interest in Myers. Operations at the Myers subsidiary are conducted primarily in California where Myers has seen significant growth.
 
 
31

 
Fiscal Year Ended December 31, 2013 Compared with Fiscal Year Ended December 31, 2012
 
   
2013
   
2012
   
% Change
 
   
(Dollar amounts in thousands)
       
Revenues
  $ 556,236     $ 630,507       (11.8 )%
Gross profit (loss)
  $ (29,944 )   $ 47,472    
NM
 
General and administrative expenses
    (40,951 )     (35,187 )     16.4  
Unusual items
    --       (511 )  
NM
 
Other income
    1,737       4,217       (58.8 )
Operating income (loss)
    (69,158 )     15,991    
NM
 
Gains on sale of securities
    91       785       (88.4 )
Interest income
    879       1,301       (32.4 )
Interest expense
    (616 )     (944 )     (34.7 )
Income (loss) before income taxes and earnings attributable to noncontrolling interests
    (68,804 )     17,133    
NM
 
Income tax (expense) benefit
    (1,222 )     579    
NM
 
Net income (loss)
    (70,026 )     17,712    
NM
 
Noncontrolling owners’ interests in earnings of subsidiaries and joint ventures
    (3,903 )     (18,009 )     (78.3 )
Net loss attributable to Sterling common stockholders
  $ (73,929 )   $ (297 )  
NM
 
Gross margin (deficit)
    (5.4 )%     7.5 %  
NM
 
Operating margin (deficit)
    (12.5 )%     2.4 %  
NM
 
Contract backlog, end of year
  $ 687,000     $ 656,000       4.7  
 
NM – Not meaningful.
 
Revenues.
 
Revenues for 2013 decreased 11.8% compared with prior year. This decrease is primarily attributable to the completion of large projects in Utah and to a lesser extent the completion of significant projects in Arizona. In 2012, a large part of our revenue in Utah related to our share of the results from a construction joint venture in which we were a minority participant. This project was substantially completed in 2012. The revenues generated in our other markets were similar to the revenues generated in the prior year.
 
Gross Profit.
 
Gross profit decreased $77.4 million in 2013 compared with the prior year. Gross margin declined to (5.4)% in 2013 from 7.5% in 2012 due to net downward revisions of estimated revenues and gross margins on construction projects in Texas and Arizona. The majority of the write-downs related to three large projects awarded prior to 2012 in Texas, which continued to have a negative impact on profitability.
 
While there are a number of factors which cause the costs incurred and gross profit realized on our contracts to vary, sometimes substantially, from our original projections, the primary factors which resulted in downward revisions in estimates in 2013 were:
 
·
conditions or contract requirements that differed from those assumed in the original bid or contract;
 
·
lower than expected productivity levels; and
 
·
delays in quickly identifying and taking measures to address issues which arose during production.
 
At December 31, 2013, we had approximately 102 contracts-in-progress which were less than 90% complete of various sizes, of different expected profitability and in various stages of completion.  The nearer a contract progresses toward completion, the more visibility we have in refining our estimate of total revenues (including incentives, delay penalties and change orders), costs and gross profit.  Thus gross profit as a percent of revenues can increase or decrease from comparable and sequential quarters due to variations among contracts and depending upon the stage of completion of contracts.
 
 
32

 
General and administrative expenses.
 
General and administrative expenses as a percentage of revenues for 2013 increased to 7.4% from 5.7% in 2012. This increase included expenses for an expanded information systems team which was hired in the fourth quarter of 2012 as well as an increase in certain employee benefit costs. The information systems team is expected to generate benefits by upgrading our information systems infrastructure, improving measurement, and focusing on process improvements that will offset their costs in the long-term. Additionally, during 2013, there were costs related to operational and financial process improvements that the Company believes are non-recurring.
 
Income taxes.
 
Our effective income tax rates for 2013 and 2012 were (1.8)% and (3.4)%, respectively. Our effective income tax rate varied from the statutory rate in 2013 primarily as a result of our deferred tax asset valuation allowance.
 
In order to determine that a valuation allowance was necessary, management assessed the available positive and negative evidence to estimate whether sufficient future taxable income would be generated to use the existing deferred tax assets. A significant piece of objective negative evidence evaluated was the cumulative loss incurred over the three-year period ended December 31, 2013. The cumulative three-year period loss that occurred in the fourth quarter of 2013 was the result of the significant write-downs recorded during the quarter. Such objective evidence limits the ability to consider other subjective evidence such as our projections for future growth. On the basis of this evaluation, as of December 31, 2013, a valuation allowance of $28.2 million has been recorded on our net deferred tax assets including federal and state net operating losses as they are not likely to be realized. The amount of the deferred tax asset considered realizable could be adjusted if objective negative evidence or cumulative losses are no longer present, and additional weight may be given to subjective evidence such as our projections for growth. In 2012, our effective tax rate was impacted by net income attributable to noncontrolling interest owners which is taxed to those owners rather than Sterling.
  
Net income attributable to noncontrolling interests.
 
The decrease in net income attributable to noncontrolling interest owner in 2013 compared with 2012 is primarily related to net income attributable to the 20% noncontrolling interest owners in RLW. The Company purchased the remaining 20% interest in RLW on December 31, 2012 which has resulted in lower net income attributable to noncontrolling interest owners during 2013. Additionally, the members of RLW, including the Company, agreed to amend RLW’s operating agreement effective January 1, 2012 to provide that any goodwill impairment, including the 2011 fourth quarter goodwill impairment, is not to be allocated to RLW for the purpose of calculating the distributions to be made to the RLW noncontrolling interest owners. This amendment resulted in an increase in the net income attributable to RLW’s noncontrolling interests of $6.7 million during 2012. This increase had a related tax impact of $2.4 million which increased the tax benefit for 2012.

 
 
33

 
Historical Cash Flows.
 
The following table sets forth information about our cash flows and liquidity (amounts in thousands):
 
   
Years Ended December 31,
 
   
2014
   
2013
   
2012
 
Net cash provided by (used in):
                 
Operating activities
  $ (10,513 )   $ (22,072 )   $ 24,789  
Capital expenditures
    (13,509 )     (14,390 )     (37,359 )
Proceeds from sale of property and equipment
    6,078       6,787       12,464  
Acquisition of noncontrolling interest
    --       --       (23,144 )
Net sales (purchases) of short-term securities
    --       48,236       (3,493 )
Distributions to noncontrolling interest owners
    (1,191 )     (3,565 )     (10,185 )
Net proceeds from stock issuance
    14,046       --       --  
Net drawdowns (repayment) on the Credit Facility
    26,793       (16,204 )     24,012  
Other
    (733 )     (62 )     (313 )
Total increase (decrease) in cash and cash equivalents
  $ 20,971     $ (1,270 )   $ (13,229 )
 
   
As of December 31,
 
   
2014
   
2013
 
Cash and cash equivalents
  $ 22,843     $ 1,872  
Working capital
  $ 52,324     $ 8,686  
 
Operating Activities.
 
Significant non-cash items included in operating activities include depreciation and amortization expense which was $18.3 million in 2014, $18.7 million in 2013 and $19.0 million in 2012. Depreciation expense has decreased slightly from 2012 to 2014 as a result of our efforts to maintain our current fleet of equipment and supplement it as necessary with leased equipment during seasonal peak operating times.
 
Besides the net loss in 2014, 2013 and 2012 and the non-cash items discussed above, other significant components of cash flows from operations were:
 
·
contracts receivable increased by $1.7 million and $6.4 million in 2014 and 2013, respectively, and decreased by $4.1 million in 2012 while the net cash flow result of billings in excess of costs and estimated earnings and costs and estimated earnings in excess of billings decreased by $27.6 million in 2014, increased by $21.6 million in 2013, and decreased by $3.7 million in 2012;
·
accounts payable increased by $5.2 million in 2014, $13.8 million in 2013 and $7.7 million in 2012;
·
accrued compensation and other liabilities decreased by $2.5 million in 2014 and increased by $4.1 million in 2013 and decreased by $2.4 million in 2012; and
·
Member’s interest subject to mandatory redemption and undistributed earnings decreased by $1.1 million as a result of an increase in undistributed earnings of $2.1 million and distributions of $3.2 million for the year ended December 31, 2014.
 
Investing Activities.
 
Capital equipment is acquired as needed to support increased levels of production activities and to replace retiring equipment. Expenditures for the replacement of certain equipment and to expand our construction fleet totaled $16.7 million in 2014 which includes $3.2 million of financed capital expenditures. Proceeds from the sale of property and equipment totaled $6.1 million for 2014 with an associated net gain of $1.0 million. For the years ended December 31, 2013 and 2012, capital expenditures totaled $14.9 million, which includes $0.5 million of financed capital expenditures, and $37.4 million, respectively, while proceeds from the sale of property and equipment totaled $6.8 million and $12.5 million, respectively, with an associated net gain of $1.8 million and $3.2 million, respectively. The level of expenditure in 2014 increased minimally by $1.8 million from 2013 as a result of management’s efforts to optimize utilization of our existing fleet of equipment based on current and projected workloads while supplementing our fleet with leased equipment during seasonal peak operating times.
 
During 2014, we owned no short-term securities. In 2013 and 2012, we had sales of short-term securities of $48.2 million and net purchases of $3.5 million, respectively. The net sales of short-term securities in 2013 were primarily used to pay the drawdown on our Credit Facility which was used to purchase the remaining 20% RLW interest in December 31, 2012 and also maintain a lower outstanding Credit Facility balance which we use to fund our operations. This sale included all of our short-term investments; therefore, at December 31, 2013, we had no short-term investment securities on our balance sheet.
 
 
34

 
Financing Activities.
 
Financing activities in 2014 consisted of net proceeds from our common stock offering of $14.0 million which was used to strengthen our balance sheet. In addition, the net drawdown on our Credit Facility of $26.8 million was used to fund our operating activities. Distributions to noncontrolling interest owners were $1.2 million for the year. Financing activities in 2013 primarily reflected a net repayment of $16.2 million and distributions to noncontrolling interest owners of $3.6 million. Financing activities in 2012 primarily reflected a net drawdown of $24.0 million and distributions to noncontrolling interest owners of $10.2 million. The amount of borrowings associated with the Credit Facility is based on the Company’s expectations of working capital requirements.
 
Liquidity and Sources of Capital.
 
The need for working capital for our business varies due to fluctuations in:
·
contract receivables and contract retentions;
·
costs and estimated earnings in excess of billings;
·
billings in excess of costs and estimated earnings;
·
the size and status of contract mobilization payments and progress billings; and
·
the amounts owed to suppliers and subcontractors.
 
Some of these fluctuations can be significant.
 
As of December 31, 2014, we had working capital of $52.3 million, an increase of $43.6 million over December 31, 2013. The increase in working capital was the result of the following (amounts in thousands):
 
Net loss
  $ (5,225 )
Depreciation and amortization
    18,348  
Capital expenditures
    (13,509 )
Proceeds from sales of property and equipment, net of gain (loss)
    5,083  
Distributions to noncontrolling interest owners
    (1,191 )
Net drawdown on the Credit Facility
    26,793  
Net proceeds from stock issued
    14,046  
Other
    (707 )
Total increase in working capital
  $ 43,638  
 
In addition to our available cash, cash equivalents and cash provided by operations, from time to time, we use borrowings under our Credit Facility with Comerica Bank to finance our capital expenditures and working capital needs.
 
On October 31, 2007, the Company and its subsidiaries entered into a new Credit Facility with Comerica Bank with a maturity date of October 31, 2012. In December 2009, the Credit Facility was amended to permit the acquisition of RLW and in November 2011, the Credit Facility was amended to extend the maturity date to September 30, 2016. Subject to the conditions under the terms of the Credit Facility, including the financial covenants and further amendments discussed below, up to $40.0 million in borrowings and letters of credit are available under the Credit Facility. Borrowings under the Credit Facility are secured by all assets of the Company, other than proceeds and other rights under our construction contracts which are pledged to our bond surety. At December 31, 2014, there was $34.6 million in borrowing outstanding under the Credit Facility; additionally, there was a letter of credit of $3.0 million outstanding which reduced availability under the Credit Facility to $2.4 million.
 
The Credit Facility is subject to our compliance with certain covenants, including financial covenants relating to leverage, tangible net worth and asset coverage. The Credit Facility contains restrictions on our ability to:
·
Make distributions and dividends;
·
Incur liens and encumbrances;
·
Incur further indebtedness;
·
Guarantee obligations;
·
Dispose of a material portion of assets or merge with a third party;
·
Make acquisitions; and
·
Make investments in securities.
 
 
35

 
At the end of the fourth quarter of 2013, we were not in compliance with the minimum tangible net worth and the leverage ratio financial covenants. As a result, subsequent to year end, we obtained a Waiver and Fourth Amendment to Credit Agreement (the “Fourth Amendment”) with our bank which waived the noncompliance with the financial covenants as of December 31, 2013 and provided less restrictive covenant requirements. The Fourth Amendment also imposed liquidity thresholds that we are required to meet in 2014. Refer to the discussion below of our revised amendment which eased our required liquidity thresholds.
 
Among other things, the Fourth Amendment reduced the borrowings available to $40 million from the previously available $50 million and has eliminated the option to increase the Credit Facility by an additional $50 million. The Fourth Amendment also modified the existing borrowing interest fee schedule and increased borrowing rates by 50 basis points to 4.75% effective December 31, 2013. In addition, if certain liquidity thresholds are not met in 2014 the interest rate may increase 200 basis points and continue to increase 100 basis points every quarter after 2015 until such thresholds are met. Furthermore, the Fourth Amendment requires the payment of a quarterly commitment fee of 0.75% per annum, which is an increase of 25 basis points, on unused availability.
 
On April 29, 2014, we obtained an amendment (the “Fifth Amendment”) with our bank which removed a requirement that we raise $20 million of new equity capital by September 30, 2014, in addition to raising $10 million of other liquidity by June 30, 2014, provided that we raise $10 million of new equity capital by May 30, 2014. As discussed below, the Company raised $14.1 million and the cash was used to repay a portion of our outstanding indebtedness under the Credit Facility. The equity raise did not reduce the Company’s borrowing capacity.
 
In addition, as discussed in Note 16 to the accompanying financial statements, on April 29, 2014, an amended “shelf” registration statement filed by the Company with the SEC became effective. Under the amended shelf registration statement, the Company may offer from time to time any combination of securities described in the prospectus in one or more offerings up to a total of $80 million, the proceeds of which may be used for working capital, capital expenditures and general corporate purposes, including future acquisitions.
 
On May 6, 2014, we closed a public offering with D.A. Davidson & Co. as sole underwriter (the “Underwriter”), pursuant to which the Underwriter purchased from the Company 2,100,000 shares of the Company’s common stock at a price of $6.90 per share. The net proceeds of $14.0 million from the offering, after deducting underwriting discounts and offering expenses, was used to repay a portion of the indebtedness outstanding under our $40 million revolving credit facility in accordance with the Fifth Amendment mentioned above.
 
On September 5, 2014, the Company and its lender amended the Credit Facility (the “Sixth Amendment”) which accomplished the following:
 
·
Removed the prohibition against acquisitions and amended the definition of Permitted Acquisition in the Credit Agreement to provide that the Company may, without the lender's consent, but subject to certain restrictions, acquire another entity or its assets for a price of up to $8 million payable in shares of the Company's common stock.
·
Modified the Company’s Tangible Net Worth requirement.
·
Eliminated the covenant which capped losses per quarter.
·
Changed the monthly Covenant Compliance Reports to quarterly reports.
 
As a result of the fourth quarter loss, we were not in compliance with the tangible net worth covenant related to the Company’s Credit Facility at December 31, 2014. On March 12, 2015, we obtained a waiver and amendment (the “Seventh Amendment”) which includes the following key modifications:
 
·
A reduction in our availability of $5 million for total availability of $35 million as of March 12, 2015;
·
A reduction in our availability of $10 million at June 1, 2015, for total availability of $25 million;
·
A reduction in our availability of $10 million at September 1, 2015, for total availability of $15 million;
·
An increase in our annual interest rate from prime rate plus 150 basis points, or 4.75%, to prime rate plus 350 basis points, or 6.75%;
·
The tangible net worth covenant is modified to include $11.3 million of available headroom from the $86.3 million of tangible net worth calculated at December 31, 2014;
·
Our first covenant test will begin at the end of April using April annualized figures; and
·
A fee of $0.4 million is due in four equal payments. The first payment was due upon execution of the Seventh Amendment and the second, third and fourth payments are due on June 30th, September 30th, and December 31st of 2015, respectively. However, any remaining unpaid fees are waived if at any point during the year we liquidate and terminate our Credit Facility a month before a payment becomes due.
 
 
36

 
We believe that we will be able to maintain compliance with all covenants under the Seventh Amendment through at least the next twelve months.
 
Due to the fourth quarter losses, which are largely due to projects constructed in Texas, and our Credit Facility’s tangible net worth debt covenant violation, we are monitoring our cash position very closely. If we are unable to return to profitability in the near future we may encounter working capital constraints. If adequate funds are not available, or are not available on acceptable terms, to alleviate our working capital constraints we may be required to sell Company equipment or property to maintain sufficient levels of working capital during our peak operating periods.
 
Average borrowings under the Credit Facility for the 2014 fiscal year were $16.9 million and the largest amount of borrowings under the Credit Facility was $36.8 million on April 21, 2014. Average borrowings under the Credit Facility for the 2013 fiscal year were $18.6 million and the largest amount of borrowings under the Credit Facility was $37.4 million on July 12, 2013.
 
Based on our average borrowings for 2014 and our 2015 forecasted cash needs, we continue to believe that the Company has sufficient liquid financial resources to fund our requirements for the next twelve months of operations, including our bonding requirements. Furthermore, the Company is continually assessing ways to increase revenues and reduce costs to improve liquidity. In 2015, our capital expenditures will be less than in 2014 and we are currently scrutinizing our fleet of equipment in order to identify and liquidate underutilized equipment.
 
Contractual Obligations.
 
The following table sets forth our fixed, non-cancelable obligations at December 31, 2014:
 
   
Payments due by period
 
   
Total
   
< 1
Year
   
1 - 3
Years
   
4 – 5
Years
   
> 5
Years
 
   
(Amounts in thousands)
 
Credit Facility
  $ 34,601     $ --     $ 34,601     $ --     $ --  
Operating leases*
    8,793       1,550       2,591       2,476       2,176  
Mortgage
    116       73       43       --       --  
Notes payable for equipment
    3,269       892       1,565       812       --  
Earn-out liability to former owner of JBC
    333       168       165       --       --  
Member’s interest subject to mandatory redemption and undistributed earnings**
    22,879       --       --       --       22,879  
    $ 69,991     $ 2,683     $ 38,965     $ 3,288     $ 25,055  
 
* Operating leases are stated at minimum annual rentals for all operating leases having initial non-cancelable lease terms in excess of one year.
** Mandatory redemption is based on the death or disability of the interest holder which is not expected to occur within the next five years. Undistributed earnings can be distributed upon unanimous consent from the members. At this time we cannot predict when such distributions will be made. Refer to Note 2 for further information.
 
Our obligations for interest are not included in the table above as these amounts vary according to the levels of debt outstanding at any time. Interest on our Credit Facility is paid monthly and fluctuates with the balances outstanding during the year, as well as with fluctuations in interest rates. In 2014, interest paid on the Credit Facility was approximately $1.1 million.
 
To manage risks of changes in the material prices and subcontracting costs used in submitting bids for construction contracts, we generally obtain firm quotations from our suppliers and subcontractors before submitting a bid. These quotations do not include any quantity guarantees, and we have no obligation for materials or subcontract services beyond those required to complete the contracts that we are awarded for which quotations have been provided.
 
As is customary in the construction business, we are required to provide surety bonds to secure our performance under construction contracts. Our ability to obtain surety bonds primarily depends upon our capitalization, working capital, past performance, management expertise and reputation and certain external factors, including the overall capacity of the surety market. Surety companies consider such factors in relationship to the amount of our backlog and their underwriting standards, which may change from time to time. We have pledged all proceeds and other rights under our construction contracts to our bond surety company. Events that affect the insurance and bonding markets may result in bonding becoming more difficult to obtain in the future, or being available only at a significantly greater cost. To date, we have not encountered difficulties or material cost increases in obtaining new surety bonds.
 
 
37

 
Capital Expenditures.
 
Capital equipment is acquired as needed by increased levels of production and to replace retiring equipment. Management expects capital expenditures in 2015 to be less than the $16.7 million incurred in 2014; however, the award of a project requiring significant purchases of equipment or other factors could result in increased expenditures.
 
Inflation.
 
Inflation generally has not had a material impact on our financial results; however, from time to time increases in oil, fuel, and steel prices have affected our cost of operations. Anticipated cost increases and reductions are considered in our bids to customers on proposed new construction projects.
 
In order to mitigate our exposure to increases in fuel prices, we have a program to hedge our exposure to increases in diesel fuel prices by entering into swap contracts for diesel fuel. We believe that the gains and losses on these contracts will tend to offset increases and decreases in the price we pay for diesel fuel and reduce the volatility of such fuel costs in our operations. As of December 31, 2014, we had diesel futures contracts for 0.1 million gallons which fixed prices at an average of $2.77 per gallon. This compares to the December 31, 2014 price for off-road ultra-low sulfur diesel published by Platts of $1.63. Due to the recent decline in oil and fuel prices, we have not entered into any new derivative instruments in 2014. In addition, we intend to retire this program when our last swap contract is settled in August 2015.
 
Where we are the successful bidder on a project, we execute purchase orders with material suppliers and contracts with subcontractors covering the prices of most materials and services, other than oil and fuel products, thereby mitigating future price increases and supply disruptions. These purchase orders and contracts do not contain quantity guarantees, and we have no obligation for materials and services beyond those required to complete the contracts with our customers. There can be no assurance that increases in prices of oil and fuel used in our business will be adequately covered by the estimated escalation we have included in our bids or derivative contracts entered into to hedge against such increases, and there can be no assurance that all of our vendors will fulfill their pricing and supply commitments under their purchase orders and contracts with the Company. We adjust our total estimated costs on our projects when we believe it is probable that we will have cost increases which will not be recovered from customers, vendors or re-engineering.
 
Off-Balance Sheet Arrangements and Joint Ventures.
 
We participate in various construction joint venture partnerships in order to share expertise, risk and resources for certain highly complex projects. The venture’s contract with the project owner typically requires joint and several liability among the joint venture partners. Although our agreements with our joint venture partners provide that each party will assume and fund its share of any losses resulting from a project, if one of our partners was unable to pay its share, we would be fully liable for such share under our contract with the project owner. Circumstances that could lead to a loss under these guarantee arrangements include a partner’s inability to contribute additional funds to the venture in the event that the project incurred a loss or additional costs that we could incur should the partner fail to provide the services and resources toward project completion that had been committed to in the joint venture agreement.
 
At December 31, 2014, there was approximately $55 million of construction work to be completed on unconsolidated construction joint venture contracts, of which $16 million represented our proportionate share. Due to the joint and several liability under our joint venture arrangements, if one of our joint venture partners fails to perform, we and the remaining joint venture partners would be responsible for completion of the outstanding work. As of December 31, 2014, we are not aware of any situation that would require us to fulfill responsibilities of our joint venture partners pursuant to the joint and several liability under our contracts.
 
Off-balance sheet arrangements related to the operating leases are included in the table in “Contractual Obligations” above.
 
New Accounting Pronouncements.
 
Refer to “Recent Accounting Pronouncements” in Note 1 to the consolidated financial statements for a discussion of new accounting pronouncements.
 
Item 7A. Quantitative and Qualitative Disclosures about Market Risk.
 
Changes in interest rates are one of our sources of market risks. Outstanding indebtedness under our Credit Facility bears interest at floating rates. The average borrowings under this facility during 2014 were $16.9 million. Based on our level of borrowings during 2014, a change of 1% to our interest rate may have a $0.2 million impact on our results from operations.
 
 
38

 
We are exposed to market risk from changes in commodity prices. In the normal course of business, we enter into derivative transactions, specifically cash flow hedges, to mitigate our exposure to diesel fuel commodity price movements. We do not participate in these transactions for trading or speculative purposes. While the use of these arrangements may limit the benefit to us of decreases in the prices of diesel fuel, it also limits the risk of adverse price movements. The following represents the outstanding contracts at December 31, 2014:
 
       
Price Per Gallon
         
Fair Value of
Derivatives at
 
Beginning
 
Ending
 
Range
   
Weighted
Average
   
Remaining
Volume
(gallons)
   
December 31,
2014
(in thousands)
 
January 1, 2015
 
August 31, 2015
  $ 2.75– 2.79     $ 2.77       100,000     $ 101  
 
See “Inflation” above regarding risks associated with materials and fuel purchases required to complete our construction contracts.
 
Item 8. Financial Statements and Supplementary Data.
 
Financial statements start on page F1.
 
Item 9. Changes in and Disagreements with Accountants on Accounting and Financial Disclosure.
 
None
 
Item 9A. Controls and Procedures.
 
Evaluation of Disclosure Controls and Procedures.
 
The Company’s principal executive officer and principal financial officer reviewed and evaluated the Company’s disclosure controls and procedures (as defined in Rules 13a-15(e) and 15d-15(e) under the Securities Exchange Act of 1934) as of December 31, 2014. Based on that evaluation, the Company’s principal executive officer and principal financial officer have concluded that the Company’s disclosure controls and procedures were effective at December 31, 2014 to ensure that the information required to be disclosed by the Company in this Annual Report on Form 10-K is recorded, processed, summarized and reported within the time periods specified in the Securities and Exchange Commission’s rules and forms and is accumulated and communicated to the Company’s management including the principal executive and principal financial officers, as appropriate to allow timely decisions regarding required disclosure.
 
Management’s Report on Internal Control over Financial Reporting.
 
The Company’s management is responsible for establishing and maintaining adequate internal control over financial reporting (as defined in Rule 13a-15(f) under the Securities Exchange Act of 1934). Under the supervision and with the participation of the Company’s management, including the principal executive officer and principal financial officer, the Company conducted an evaluation of the effectiveness of internal control over financial reporting at December 31, 2014. In making this assessment, management used the criteria set forth by the Committee of Sponsoring Organizations of the Treadway Commission (COSO) in the 2013 Internal Control-Integrated Framework. The Company’s management has concluded that, at December 31, 2014, the Company’s internal control over financial reporting is effective based on these criteria.
 
Changes in Internal Control over Financial Reporting.
 
We maintain a system of internal control over financial reporting that is designed to provide reasonable assurance regarding the reliability of financial reporting and the preparation of financial statements for external purposes in accordance with accounting principles generally accepted in the United States. Based on the most recent evaluation we have concluded that no significant changes in our internal control over financial reporting occurred during the three months ended December 31, 2014 that have materially affected or are reasonably likely to materially affect, our internal control over financial reporting.
 
Inherent Limitations on Effectiveness of Controls.
 
Internal control over financial reporting may not prevent or detect all errors and all fraud. Also, projections of any evaluation of effectiveness of internal control to future periods are subject to the risk that controls may become inadequate because of changes in conditions, or that the degree of compliance with the policies or procedures may deteriorate.
 
Item 9B. Other Information.
 
None.
 
 
39

 
PART III
 
Item 10. Directors, Executive Officers and Corporate Governance.
 
The information required in this item is contained in the Company’s proxy statement for its Annual Meeting of Stockholders to be held on May 8, 2015 and is incorporated herein by reference. The information can be found under the following headings in the proxy statement:
 
Item 10 Information
 
Location or Heading
in the Proxy Statement
Directors
 
Election of Directors (Proposal 1) Board Operations
Compliance With Section 16(a) of the Exchange Act
 
Stock Ownership Information
Code of Ethics
 
The Corporate Governance & Nominating Committee
Communication with the Board; nominations; Board and committee meetings; committees of the Board; Board leadership and risk oversight; and director compensation.
 
The Board of Directors
 
Information relating to the Company’s executive officers is set forth at the end of Part I of this Report under the caption “Executive Officers of the Registrant” and is incorporated herein by reference.
 
Item 11. Executive Compensation
 
The information required in this item is contained in the Company's proxy statement for its Annual Meeting of Stockholders to be held on May 8, 2015 and is incorporated herein by reference. The information can be found under the headings Executive Compensation and Board Operations in the proxy statement.
 
Item 12. Security Ownership of Certain Beneficial Owners and Management, and Related Stockholder Matters.
 
The information required in this item is contained in the Company’s proxy statement for its Annual Meeting of Stockholders to be held on May 8, 2015 and is incorporated herein by reference.
 
·
Equity Compensation Plan Information can be found in the proxy statement under the heading Executive Compensation.
·
Information regarding the ownership of the Company’s common stock can be found in the proxy statement under the heading Stock Ownership Information.
 
Item 13. Certain Relationships and Related Transactions, and Director Independence.
 
The information required in this item is contained in the Company’s proxy statement for its Annual Meeting of Stockholders to be held on May 8, 2015 and is incorporated herein by reference.
 
·
Information regarding any relationships between directors and officers and the Company can be found in the proxy statement under the heading Transactions with Related Persons.
·
Information about director independence can be found in the proxy statement under the heading Election of Directors (Proposal 1).
 
Item 14. Principal Accountant Fees and Services.
 
The information required in this item is contained in the Company’s proxy statement for its Annual Meeting of Stockholders to be held on May 8, 2015 and is incorporated herein by reference. The information can be found in the proxy statement under the heading Information about Audit Fees and Audit Services.
 
 
40

 
PART IV
 
Item 15. Exhibits and Financial Statement Schedules.
 
The following Financial Statements and Financial Statement Schedules are filed with this Report:
 
Financial Statements:
 
Reports of the Company’s Independent Registered Public Accounting Firm
 
Consolidated Balance Sheets as of December 31, 2014 and 2013
 
Consolidated Statements of Operations for the years ended December 31, 2014, 2013 and 2012
 
Consolidated Statements of Comprehensive Income (Loss) for the years ended December 31, 2014, 2013 and 2012
 
Consolidated Statements of Cash Flows for the years ended December 31, 2014, 2013 and 2012
 
Consolidated Statements of Stockholders’ Equity for the years ended December 31, 2014, 2013 and 2012
 
Financial Statement Schedules.
 
None.
 
Exhibits.
 
The following exhibits are filed with this Report.
 
Explanatory Note
 
Prior to changing its name to Sterling Construction Company, Inc. in November 2001, the Company’s name was Oakhurst Company, Inc. References in the following exhibit list use the name of the Company in effect at the date of the exhibit.


Number
Exhibit Title
2.1.1
Purchase Agreement, dated as of December 3, 2009, by and among Kip Wadsworth, Ty Wadsworth, Con Wadsworth, Tod Wadsworth and Sterling Construction Company, Inc. (incorporated by reference to Exhibit 2.1 to Sterling Construction Company, Inc.'s Current Report on Form 8-K, filed on December 3, 2009 (SEC File No. 1-31993)).
3.1
Certificate of Incorporation of Sterling Construction Company, Inc. as amended through May 9, 2014 (incorporated by reference to Exhibit 3 to Sterling Construction Company, Inc.'s Current Report on Form 8-K, filed on May 13, 2014 (SEC File No. 1-31993)).
3.2
Bylaws of Sterling Construction Company, Inc. as amended through March 13, 2008 (incorporated by reference to Exhibit 3.1 to Sterling Construction Company, Inc.'s Current Report on Form 8-K, filed on March 19, 2008 (SEC File No. 1-31993)).
4.1
Form of Common Stock Certificate of Sterling Construction Company, Inc. (incorporated by reference to Exhibit 4.5 to Sterling Construction Company, Inc.'s Form 8-A, filed on January 11, 2006 (SEC File No. 1-31993)).
10.1.1#
The Sterling Construction Company, Inc. Stock Incentive Plan as amended through May 9, 2014 (incorporated by reference to Exhibit 10.2 to Sterling Construction Company, Inc.'s. Current Report on Form 8-K, filed on May 13, 2014 (SEC File No. 1-31993)).
10.1.2#
2014 Sterling Incentive Compensation Plan (incorporated by reference to Exhibit 10.1 to Sterling Construction Company, Inc.’s Current Report on Form 8-K, filed on May 13, 2014 (SEC File No. 1-31993)).
10.2#
Forms of Stock Option Agreement under the Oakhurst Company, Inc. 2001 Stock Incentive Plan (now known as The Sterling Construction Company, Inc. Stock Incentive Plan) (incorporated by reference to Exhibit 10.52 to Sterling Construction Company, Inc.'s Annual Report on Form 10-K for the year ended December 31, 2004, filed on March 29, 2005 (SEC File No. 1-31993)).
10.3#
Summary of standard compensation arrangements for non-employee directors of Sterling Construction Company, Inc. adopted by the Board of Directors on May 9, 2014 (incorporated by reference to Exhibit 10.1 to Sterling Construction Company, Inc.'s Quarterly Report on Form 10-Q for the quarter ended June 30, 2014, filed on August 11, 2014 (SEC File No. 1-31993)).
 
 
41

 
 
10.4.1
Credit Agreement by and among Sterling Construction Company, Inc., Texas Sterling Construction Co., Oakhurst Management Corporation and Comerica Bank and the other lenders from time to time party thereto, and Comerica Bank as administrative agent for the lenders, dated as of October 31, 2007 (incorporated by reference to Exhibit 10.1 to Sterling Construction Company, Inc.'s Current Report on Form 8-K, Amendment No. 1 filed on November 21, 2007 (SEC File No. 1-31993)).
10.4.2
Security Agreement by and among Sterling Construction Company, Inc., Texas Sterling Construction Co., Oakhurst Management Corporation and Comerica Bank as administrative agent for the lenders, dated as of October 31, 2007 (incorporated by reference to Exhibit F to Exhibit 10.4 to Sterling Construction Company, Inc.'s Quarterly Report on Form 10-Q, filed on November 9, 2009 (SEC File No. 1-31993)).
10.4.3
Joinder Agreement by Road and Highway Builders, LLC and Road and Highway Builders Inc. dated as of October 31, 2007 (incorporated by reference to Exhibit 10.3 to Sterling Construction Company, Inc.'s Current Report on Form 8-K, Amendment No. 1 filed on November 21, 2007 (SEC File No. 1-31993)).
10.4.4
Consent and Second Amendment to Credit Agreement by and among Sterling Construction Company, Inc., its subsidiaries, and Comerica Bank as Agent, Lender, Swing Line Lender and Issuing Lender dated as of November 8, 2011 (incorporated by reference to Exhibit 10.2 to Sterling Construction Company, Inc.'s Quarterly Report on Form 10-Q filed on November 8, 2011 (SEC File No. 1-31993)).
10.4.5
Waiver and Third Amendment to Credit Agreement by and among Sterling Construction Company, Inc., and certain of its subsidiaries, certain of the Lenders, and Comerica Bank as administrative agent for the lenders, dated as of August 8, 2013 (incorporated by reference to Exhibit 10.4.5 to Sterling Construction Company, Inc.'s Annual Report on Form 10-K filed on March 17, 2014 (SEC File No. 1-31993)).
10.4.6
Waiver and Fourth Amendment to Credit Agreement dated as of March 14, 2014 by and among Sterling Construction Company, Inc., certain of its affiliates and subsidiaries, certain of the Lenders, and Comerica Bank as Administrative Agent (incorporated by reference to Exhibit 10.4.6 to Sterling Construction Company, Inc.'s Annual Report on Form 10-K filed on March 17, 2014 (SEC File No. 1-31993)).
10.4.7
Fifth Amendment to Credit Agreement dated as of April 29, 2014 by and among Sterling Construction Company, Inc., Comerica Bank, as administrative agent and certain of the lenders (incorporated by reference to Exhibit 10.1 to Sterling Construction Company, Inc.'s Current Report on Form 8-K filed on April 30, 2014 (SEC File No. 1-31993)).
10.4.8
Sixth Amendment to Credit Agreement dated as of September 5, 2014 by and among Sterling Construction Company, Inc., Comerica Bank, as administrative agent and certain of the lenders (incorporated by reference to Exhibit 10.1 to Sterling Construction Company, Inc.'s Current Report on Form 8-K filed on September 5, 2014 (SEC File No. 1-31993)).
10.5.1#
Employment Agreement dated as of March 17, 2006 between Sterling Construction Company, Inc. and Roger M. Barzun (incorporated by reference to Exhibit 10.11 to Sterling Construction Company, Inc.'s Annual Report on Form 10-K/A for the year ended December 31, 2009, filed on March 18, 2010 (SEC File No. 1-31993)).
10.5.2#
Amendment dated January 18, 2012 of the Employment Agreement dated as of March 17, 2006 between Sterling Construction Company, Inc. and Roger M. Barzun (incorporated by reference to Exhibit 10.7.1 to Sterling Construction Company, Inc.'s Annual Report on Form 10-K filed on March 17, 2014 (SEC File No. 1-31993)).
10.6#
Employment Agreement dated December 28, 2012 between Ralph L. Wadsworth Construction Company, LLC and Con L. Wadsworth (incorporated by reference to Exhibit 10.9 to Sterling Construction Company, Inc.'s Annual Report on Form 10-K filed on March 17, 2014 (SEC File No. 1-31993)).
10.7#
Employment Agreement dated as of September 1, 2012 between Sterling Construction Company, Inc. and Peter E. MacKenna (incorporated by reference to Exhibit 10.1 to Sterling Construction Company, Inc.'s Quarterly Report on Form 10-Q for the quarter ended September 30, 2012, filed on November 8, 2012 (SEC File No. 1-31993)).
 
 
42

 
 
10.8.2#
Amendment to the Employment Agreement of Thomas R. Wright dated September 26, 2014 (incorporated by reference to Exhibit 10.1 to Sterling Construction Company, Inc.'s Current Report on Form 8-K filed on September 29, 2014 (SEC File No. 1-31993)).
10.9.1#
Program Description — 2015 Short-Term Incentive Compensation Program & 2015 Long-Term Incentive Compensation Program (incorporated by reference to Exhibit 10.1 to Sterling Construction Company, Inc.'s Current Report on Form 8-K filed on December 17, 2014 (SEC File No. 1-31993))
10.9.2#
Form of Long-Term Incentive Program Award Agreement (incorporated by reference to Exhibit 10.2 to Sterling Construction Company, Inc.'s Current Report on Form 8-K filed on December 17, 2014 (SEC File No. 1-31993)).
10.9.3#*
Amended form of Long-Term Incentive Program Award Agreement.
10.10#*
Employment Agreement dated as of March 9, 2015 between Sterling Construction Company, Inc. and Paul J. Varello.
21
Subsidiaries of Sterling Construction Company, Inc.:
 
 
Name
State of Incorporation or Organization
 
 
Texas Sterling Construction Co.
Delaware
 
 
Road and Highway Builders, LLC
Nevada
 
 
Road and Highway Builders Inc.
Nevada
 
 
RHB Properties, LLC
Nevada
 
 
Road and Highway Builders of California, Inc.
California
 
 
Sterling Hawaii Asphalt, LLC
Hawaii
 
 
Ralph L. Wadsworth Construction Company, LLC
Utah
 
 
Ralph L. Wadsworth Construction Co. LP
California
 
 
J. Banicki Construction, Inc.
Arizona
 
 
Myers & Sons Construction, L.P.
California
 
23.1*
Consent of Grant Thornton, LLP
 
31.1*
Certification of Paul J. Varello, Chief Executive Officer of Sterling Construction Company, Inc.
31.2*
Certification of Thomas R. Wright, Executive Vice President & Chief Financial Officer of Sterling Construction Company, Inc.
32.1*
Certification pursuant to Section 1350 of Chapter 63 of Title 18 of the United States Code (18 U.S.C. 1350) of Paul J. Varello Chief Executive Officer, and Thomas R. Wright, Executive Vice President & Chief Financial Officer.
95.1*
Mine Safety Disclosure
 
 
 
 
 
 
# Management contract or compensatory plan or arrangement.
 
 
* Filed herewith.
 
 
43

 
SIGNATURES
 
Pursuant to the requirements of Section 13 or 15(d) of the Securities Exchange Act of 1934, the registrant has duly caused this Report to be signed on its behalf by the undersigned, thereunto duly authorized.
 
Sterling Construction Company, Inc.
 
Date: March 16, 2015
By:
/s/ Paul J. Varello
 
   
Paul J. Varello, Chief Executive Officer
 
   
(duly authorized officer)
 
 
Pursuant to the requirements of the Securities Exchange Act of 1934, this Report has been signed below by the following persons on behalf of the registrant and in the capacities and on the dates indicated.
 
Signature
Title
Date
/s/ Milton L. Scott
Chairman of the Board of Directors
March 16, 2015
Milton L. Scott
   
     
/s/ Paul J. Varello 
Chief Executive Officer (principal executive officer)
March 16, 2015
Paul J. Varello
   
     
/s/ Thomas R. Wright 
Executive Vice President & Chief Financial Officer
March 16, 2015
Thomas R. Wright
(principal financial officer and principal accounting officer), Treasurer  
     
/s/ Marian M. Davenport 
Director
March 16, 2015
Marian M. Davenport
   
     
/s/Maarten D. Hemsley 
Director
March 16, 2015
Maarten D. Hemsley
   
     
/s/ Charles R. Patton 
Director
March 16, 2015
Charles R. Patton
   
     
/s/ Richard O. Schaum 
Director
March 16, 2015
Richard O. Schaum
   
 
 
 
44

 
REPORT OF INDEPENDENT REGISTERED PUBLIC ACCOUNTING FIRM
 


 
To the Board of Directors and Stockholders
Sterling Construction Company, Inc.:
 
We have audited the accompanying consolidated balance sheets of Sterling Construction Company, Inc. (a Delaware corporation) and subsidiaries (the “Company”) as of December 31, 2014 and 2013, and the related consolidated statements of operations, comprehensive income (loss), stockholders’ equity and cash flows for each of the three years in the period ended December 31, 2014. These financial statements are the responsibility of the Company’s management. Our responsibility is to express an opinion on these financial statements based on our audits.
 
We conducted our audits in accordance with the standards of the Public Company Accounting Oversight Board (United States). Those standards require that we plan and perform the audit to obtain reasonable assurance about whether the financial statements are free of material misstatement. An audit includes examining, on a test basis, evidence supporting the amounts and disclosures in the financial statements. An audit also includes assessing the accounting principles used and significant estimates made by management, as well as evaluating the overall financial statement presentation. We believe that our audits provide a reasonable basis for our opinion.
 
In our opinion, the consolidated financial statements referred to above present fairly, in all material respects, the financial position of Sterling Construction Company, Inc. and subsidiaries as of December 31, 2014 and 2013, and the results of their operations and their cash flows for each of the three years in the period ended December 31, 2014 in conformity with accounting principles generally accepted in the United States of America.
 
We also have audited, in accordance with the standards of the Public Company Accounting Oversight Board (United States), the Company’s internal control over financial reporting as of December 31, 2014, based on criteria established in the 2013 Internal Control—Integrated Framework issued by the Committee of Sponsoring Organizations of the Treadway Commission (COSO), and our report dated March 16, 2015 expressed an unqualified opinion.
 
/s/ GRANT THORNTON LLP
 
Houston, Texas
March 16, 2015


 
 
F1

 
REPORT OF INDEPENDENT REGISTERED PUBLIC ACCOUNTING FIRM
 
To the Board of Directors and Stockholders
Sterling Construction Company, Inc.:
 
We have audited the internal control over financial reporting of Sterling Construction Company, Inc. (a Delaware corporation) and subsidiaries (the “Company”) as of December 31, 2014 based on criteria established in the 2013 Internal Control—Integrated Framework issued by the Committee of Sponsoring Organizations of the Treadway Commission (COSO). The Company’s management is responsible for maintaining effective internal control over financial reporting and for its assessment of the effectiveness of internal control over financial reporting, included in the accompanying Management’s Report on Internal Control over Financial Reporting. Our responsibility is to express an opinion on the Company’s internal control over financial reporting based on our audit.
 
We conducted our audit in accordance with the standards of the Public Company Accounting Oversight Board (United States). Those standards require that we plan and perform the audit to obtain reasonable assurance about whether effective internal control over financial reporting was maintained in all material respects. Our audit included obtaining an understanding of internal control over financial reporting, assessing the risk that a material weakness exists, testing and evaluating the design and operating effectiveness of internal control based on the assessed risk, and performing such other procedures as we considered necessary in the circumstances. We believe that our audit provides a reasonable basis for our opinion.
 
A company’s internal control over financial reporting is a process designed to provide reasonable assurance regarding the reliability of financial reporting and the preparation of financial statements for external purposes in accordance with generally accepted accounting principles. A company’s internal control over financial reporting includes those policies and procedures that (1) pertain to the maintenance of records that, in reasonable detail, accurately and fairly reflect the transactions and dispositions of the assets of the company; (2) provide reasonable assurance that transactions are recorded as necessary to permit preparation of financial statements in accordance with generally accepted accounting principles, and that receipts and expenditures of the company are being made only in accordance with authorizations of management and directors of the company; and (3) provide reasonable assurance regarding prevention or timely detection of unauthorized acquisition, use, or disposition of the company’s assets that could have a material effect on the financial statements.
 
Because of its inherent limitations, internal control over financial reporting may not prevent or detect misstatements. Also, projections of any evaluation of effectiveness to future periods are subject to the risk that controls may become inadequate because of changes in conditions, or that the degree of compliance with the policies or procedures may deteriorate.
 
In our opinion, the Company maintained, in all material respects, effective internal control over financial reporting as of December 31, 2014, based on criteria established in the 2013 Internal Control – Integrated Framework issued by COSO.
 
We also have audited, in accordance with the standards of the Public Company Accounting Oversight Board (United States), the consolidated financial statements of the Company as of and for the year ended December 31, 2014, and our report dated March 16, 2015 expressed an unqualified opinion on those financial statements.
 
/s/ GRANT THORNTON LLP
 
Houston, Texas
March 16, 2015
 
 
F2

 
STERLING CONSTRUCTION COMPANY, INC. & SUBSIDIARIES
CONSOLIDATED BALANCE SHEETS
As of December 31, 2014 and 2013
(Amounts in thousands, except share and per share data)
 
 
   
2014
   
2013
 
ASSETS
           
Current assets:
           
Cash and cash equivalents
  $ 22,843     $ 1,872  
Contracts receivable, including retainage
    78,896       77,245  
Costs and estimated earnings in excess of billings on uncompleted contracts
    33,403       11,684  
Inventories
    7,401       6,189  
Receivables from and equity in construction joint ventures
    9,153       6,118  
Other current assets
    5,278       11,377  
Total current assets
    156,974       114,485  
Property and equipment, net
    87,098       93,683  
Goodwill
    54,820       54,820  
Other assets, net
    7,559       10,030  
Total assets
  $ 306,451     $ 273,018  
LIABILITIES AND EQUITY
               
Current liabilities:
               
Accounts payable
  $ 66,792     $ 61,599  
Billings in excess of costs and estimated earnings on uncompleted contracts
    25,649       31,576  
Current maturities of long-term debt
    965       134  
Income taxes payable
    1,868       2,035  
Accrued compensation
    5,169       5,755  
Current obligation for noncontrolling owners’ interest in subsidiaries and joint ventures
    -       196  
Other current liabilities
    4,207       4,504  
Total current liabilities
    104,650       105,799  
Long-term liabilities:
               
Long-term debt, net of current maturities
    37,021       8,331  
Member’s interest subject to mandatory redemption and undistributed earnings
    22,879       23,989  
Other long-term liabilities
    753       2,105  
Total long-term liabilities
    60,653       34,425  
Commitments and contingencies (Note 13)
               
Equity:
               
Sterling stockholders’ equity:
               
Preferred stock, par value $0.01 per share; 1,000,000 shares authorized, none issued
    -       -  
Common stock, par value $0.01 per share; 28,000,000 shares authorized,
18,802,679 and 16,657,754 shares issued
    188       167  
Additional paid in capital
    205,697       190,926  
Retained deficit
    (72,098 )     (62,317 )
Accumulated other comprehensive (loss) income
    (101 )     117  
Total Sterling common stockholders’ equity
    133,686       128,893  
Noncontrolling interests
    7,462       3,901  
Total equity
    141,148       132,794  
Total liabilities and equity
  $ 306,451     $ 273,018  
 
The accompanying notes are an integral part of these consolidated financial statements.
 
 
F3

 
STERLING CONSTRUCTION COMPANY, INC. & SUBSIDIARIES
CONSOLIDATED STATEMENTS OF OPERATIONS
For the years ended December 31, 2014, 2013 and 2012
(Amounts in thousands, except per share data)
 
 
   
2014
   
2013
   
2012
 
Revenues
  $ 672,230     $ 556,236     $ 630,507  
Cost of revenues
    (639,809 )     (586,180 )     (583,035 )
Gross profit (loss)
    32,421       (29,944 )     47,472  
General and administrative expenses
    (36,897 )     (40,951 )     (35,187 )
Direct costs of acquisitions
    -       -       (202 )
Provision for loss on lawsuit
    -       -       (309 )
Other operating income, net
    252       1,737       4,217  
Operating (loss) income
    (4,224 )     (69,158 )     15,991  
Gain on sale of securities
    -       91       785  
Interest income
    754       879       1,301  
Interest expense
    (1,123 )     (616 )     (944 )
(Loss) income before income taxes and earnings attributable to noncontrolling interests
    (4,593 )     (68,804 )     17,133  
Income tax (expense) benefit
    (632 )     (1,222 )     579  
Net (loss) income
    (5,225 )     (70,026 )     17,712  
Noncontrolling owners’ interests in earnings of subsidiaries and joint ventures
    (4,556 )     (3,903 )     (18,009 )
Net loss attributable to Sterling common stockholders
  $ (9,781 )   $ (73,929 )   $ (297 )
Net loss per share attributable to Sterling common stockholders:
                       
Basic and diluted
  $ (0.54 )   $ (4.91 )   $ (0.26 )
Weighted average number of common shares outstanding used in computing per share amounts:
                       
Basic and diluted
    18,063,466       16,635,179       16,420,886  
 
The accompanying notes are an integral part of these consolidated financial statements.
 
 
F4

 
STERLING CONSTRUCTION COMPANY, INC. & SUBSIDIARIES
CONSOLIDATED STATEMENTS OF COMPREHENSIVE INCOME (LOSS)
For the years ended December 31, 2014, 2013 and 2012
(Amounts in thousands)


   
2014
   
2013
   
2012
 
Net loss attributable to Sterling common stockholders
  $ (9,781 )   $ (73,929 )   $ (297 )
Net income attributable to noncontrolling interest included in equity
    4,556       1,879       1,068  
Net income attributable to noncontrolling interest included in liabilities
    -       2,024       16,941  
Add /(deduct) other comprehensive income, net of tax:
                       
Realized gain from available-for-sale securities
    -       (90 )     (510 )
Change in unrealized holding gain (loss) on available-for-sale securities
    -       (601 )     560  
Realized (gain) loss from settlement of derivatives
    137       (48 )     43  
Change in the effective portion of unrealized (loss) gain in fair market value of derivatives
    (355 )     160       107  
Comprehensive (loss) income
  $ (5,443 )   $ (70,605 )   $ 17,912  


 
 
 
The accompanying notes are an integral part of these consolidated financial statements.

 
F5

 
STERLING CONSTRUCTION COMPANY, INC. & SUBSIDIARIES
CONSOLIDATED STATEMENT OF STOCKHOLDERS’ EQUITY
For the years ended December 31, 2014, 2013 and 2012
(Amounts in thousands)


    STERLING CONSTRUCTION COMPANY, INC.
STOCKHOLDERS
             
   
Common Stock
   
Addi-
tional
Paid in
   
Retained
Earnings
   
Accu-
mulated
Other
Compre-
hensive
Income
   
Noncontrolling
       
   
Shares
   
Amount
   
Capital
   
(Deficit)
   
(Loss)
   
Interests
   
Total
 
Balance at January 1, 2012
    16,321     $ 163     $ 196,143     $ 16,509     $ 496     $ 1,527     $ 214,838  
Net (loss) income
    -       -       -       (297 )     -       1,068       771  
Other comprehensive income
    -       -       -       -       200       -       200  
Stock issued upon option and warrant exercises
    24       -       66       -       -       -       66  
Tax impact from exercise of stock options
    -       -       (79 )     -       -       -       (79 )
Issuance and amortization of restricted stock
    150       2       694       -       -       -       696  
Revaluation of noncontrolling interest liabilities and other, net of tax
    -       -       243       (3,992 )     -       (40 )     (3,789 )
Distribution to owners
    -       -       -       -       -       (117 )     (117 )
Balance at December 31, 2012
    16,495       165       197,067       12,220       696       2,438       212,586  
Net (loss) income
    -       -       -       (73,929 )     -       1,879       (72,050 )
Other comprehensive loss
    -       -       -       -       (579 )     -       (579 )
Stock issued upon option exercises
    9       -       26       -       -       -       26  
Tax impact from exercise of stock options
    -       -       (15 )     -       -       -       (15 )
Issuance and amortization of common and restricted stock
    154       2       926       -       -       -       928  
Revaluation of noncontrolling interest and other, net of tax
    -       -       (7,078 )     (608 )     -       -       (7,686 )
Distribution to owners
    -       -       -       -       -       (416 )     (416 )
Balance at December 31, 2013
    16,658       167       190,926       (62,317 )     117       3,901       132,794  
Net (loss) income
    -       -       -       (9,781 )     -       4,556       (5,225 )
Other comprehensive loss
    -       -       -       -       (218 )     -       (218 )
Stock issued upon option exercises
    4       -       12       -       -       -       12  
Issuance and amortization of restricted stock
    41       -       849       -       -       -       849  
Distribution to owners
    -       -       -       -       -       (994 )     (994 )
Stock issued in equity offering, net of expense
    2,100       21       14,025       -       -       -       14,046  
Other
    -       -       (115 )     -       -       (1 )     (116 )
Balance at December 31, 2014
    18,803     $ 188     $ 205,697     $ (72,098 )   $ (101 )   $ 7,462     $ 141,148  
 
The accompanying notes are an integral part of these consolidated financial statements.
 
 
F6

 
STERLING CONSTRUCTION COMPANY, INC. & SUBSIDIARIES
CONSOLIDATED STATEMENTS OF CASH FLOWS
For the years ended December 31, 2014, 2013 and 2012
(Amounts in thousands)


   
2014
   
2013
   
2012
 
Cash flows from operating activities:
                 
Net loss attributable to Sterling common stockholders
  $ (9,781 )   $ (73,929 )   $ (297 )
Plus: Noncontrolling owners’ interests in earnings of subsidiaries and joint ventures
    4,556       3,903       18,009  
Net (loss) income
    (5,225 )     (70,026 )     17,712  
Adjustments to reconcile net (loss) income to net cash (used in) provided by operating activities:
                       
Depreciation and amortization
    18,348       18,650       18,997  
Gain on disposal of property and equipment
    (995 )     (1,837 )     (3,184 )
Deferred tax expense (benefit)
    -       5,150       (1,167 )
Interest expense accreted on noncontrolling interests
    -       -       993  
Stock-based compensation expense
    849       928       694  
Gain on sale of securities
    -       (91 )     (785 )
Tax impact from exercise of stock options and restricted stock
    -       15       79  
Changes in operating assets and liabilities:
                       
Contracts receivable
    (1,651 )     (6,430 )     4,060  
Costs and estimated earnings in excess of billings on uncompleted contracts
    (21,719 )     8,908       (4,083 )
Receivables from and equity in construction joint ventures
    (3,035 )     4,887       (4,948 )
Income tax receivable
    4,784       (6,011 )     -  
Other current assets
    2,480       (6,722 )     (9,234 )
Accounts payable
    5,192       13,794       7,730  
Billings in excess of costs and estimated earnings on uncompleted contracts
    (5,927 )     12,658       335  
Accrued compensation and other liabilities
    (2,504 )     4,055       (2,410 )
Member’s interest subject to mandatory redemption and undistributed earnings
    (1,110 )     -       -  
Net cash (used in) provided by operating activities
    (10,513 )     (22,072 )     24,789  
Cash flows from investing activities:
                       
Acquisition of noncontrolling interests
    -       -       (23,144 )
Additions to property and equipment
    (13,509 )     (14,390 )     (37,359 )
Proceeds from sale of property and equipment
    6,078       6,787       12,464  
Purchases of short-term securities, available-for-sale
    -       (1,638 )     (30,154 )
Sales of short-term securities, available-for-sale
    -       49,874       26,661  
Net cash (used in) provided by investing activities
    (7,431 )     40,633       (51,532 )
Cash flows from financing activities:
                       
Cumulative daily drawdowns – Credit Facility
    330,338       219,026       75,012  
Cumulative daily repayments – Credit Facility
    (303,545 )     (235,230 )     (51,000 )
Distributions to noncontrolling interest owners
    (1,191 )     (3,565 )     (10,185 )
Net proceeds from stock issued
    14,046       -       -  
Issuance of common stock pursuant to warrants and options exercised
    12       26       68  
Tax impact from exercise of stock options
    -       (15 )     (79 )
Other
    (745 )     (73 )     (302 )
Net cash provided by (used in) financing activities
    38,915       (19,831 )     13,514  
Net increase (decrease) in cash and cash equivalents
    20,971       (1,270 )     (13,229 )
Cash and cash equivalents at beginning of period
    1,872       3,142       16,371  
Cash and cash equivalents at end of period
  $ 22,843     $ 1,872     $ 3,142  
Supplemental disclosures of cash flow information:
                       
Cash paid during the period for interest
  $ 1,075     $ 595     $ 88  
Cash paid during the period for income taxes
  $ 1     $ 170     $ 2,990  
Non-cash items:
                       
Revaluation of noncontrolling interests
  $ -     $ (7,686 )   $ 3,992  
Issuance of noncontrolling interest in RHB in exchange for net assets of acquired companies
  $ -     $ -     $ 9,767  
Goodwill adjustments
  $ -     $ -     $ 410  
Transportation and construction equipment acquired through financing arrangements
  $ 3,159     $ 510     $ -  
 
The accompanying notes are an integral part of these consolidated financial statements.
 
 
F7

 
STERLING CONSTRUCTION COMPANY, INC. & SUBSIDIARIES
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS
 
1.  
Summary of Business and Significant Accounting Policies
 
Business Summary
 
Sterling Construction Company, Inc. (“Sterling” or “the Company”), a Delaware corporation, is a leading heavy civil construction company that specializes in the building and reconstruction of transportation and water infrastructure projects in Texas, Utah, Nevada, Arizona, California, Hawaii and other states in which there are construction opportunities. Our transportation infrastructure projects include highways, roads, bridges and light rail, and our water infrastructure projects include water, wastewater and storm drainage systems. We perform the majority of the work required by our contracts with our own crews and equipment.
 
Sterling owns equity interests in the following subsidiaries: Texas Sterling Construction Co. (“TSC”); Road and Highway Builders, LLC (“RHB”); Road and Highway Builders Inc. (“RHB Inc”); Road and Highway Builders of California, Inc. (“RHBCa”); RHB Properties, LLC (“RHBP”); Ralph L. Wadsworth Construction Company, LLC (“RLW”); Ralph L. Wadsworth Construction Co., LP (“RLWLP”); J. Banicki Construction, Inc.(“JBC”); Myers & Sons Construction, L.P. (“Myers”); and Sterling Hawaii Asphalt (“SHA”). TSC, RHB, RHB Ca, RLW, JBC and Myers perform construction contracts, RHB Inc. produces aggregates from a leased quarry, primarily for use by RHB, and SHA produces asphalt for use by RHB and has minimal sales to third parties. RHBP and RLWLP are dormant entities.
 
Significant Accounting Policies
 
Principles of Consolidation
 
The accompanying consolidated financial statements include the accounts of subsidiaries and construction joint ventures in which the Company has a greater than 50% ownership interest or otherwise controls such entities. For investments in subsidiaries and construction joint ventures that are not wholly-owned, but where the Company exercises control, the equity held by the remaining owners and their portions of net income (loss) are reflected in the balance sheet line item “Noncontrolling interests” in “Equity” and the statement of operations line item “Noncontrolling owners’ interests in earnings of subsidiaries and joint ventures,” respectively. All significant intercompany accounts and transactions have been eliminated in consolidation. For all years presented, the Company had no subsidiaries where its ownership interests were less than 50%.
 
Where the Company is a noncontrolling joint venture partner, and otherwise not required to consolidate the joint venture entity, its share of the operations of such construction joint venture is accounted for on a pro rata basis in the consolidated statements of operations and as a single line item (“Receivables from and equity in construction joint ventures”) in the consolidated balance sheets. This method is an acceptable modification of the equity method of accounting which is a common practice in the construction industry. Refer to Note 6 for further information regarding the Company’s construction joint ventures.
 
Under accounting principles generally accepted in the United States (“GAAP”), the Company must determine whether each entity, including joint ventures in which it participates, is a variable interest entity. This determination focuses on identifying which owner or joint venture partner, if any, has the power to direct the activities of the entity and the obligation to absorb losses of the entity or the right to receive benefits from the entity disproportionate to its interest in the entity, which could have the effect of requiring us to consolidate the entity in which we have a noncontrolling variable interest. Refer to Note 3 for further information regarding the Company’s consolidated variable interest entity.
 
Use of Estimates
 
The preparation of financial statements in conformity with GAAP requires management to make estimates and assumptions that affect the reported amounts of assets and liabilities, the disclosure of contingent assets and liabilities at the date of the financial statements, and the reported amounts of revenues and expenses during the reporting period. Certain of the Company’s accounting policies require higher degrees of judgment than others in their application. These include the recognition of revenue and earnings from construction contracts under the percentage-of-completion method, the valuation of long-term assets (including goodwill), and income taxes. Management continually evaluates all of its estimates and judgments based on available information and experience; however, actual amounts could differ from those estimates.
 
 
F8

 
Revenue Recognition
 
The Company is a general contractor which engages in various types of heavy civil construction projects principally for public (government) owners. Credit risk is minimal with public owners since the Company ascertains that funds have been appropriated by the governmental project owner prior to commencing work on such projects. While most public contracts are subject to termination at the election of the government entity, in the event of termination the Company is entitled to receive the contract price for completed work and reimbursement of termination-related costs. Credit risk with private owners is minimized because of statutory mechanics liens, which give the Company high priority in the event of lien foreclosures following financial difficulties of private owners. Refer to Note 18 for further information regarding the Company’s concentration of risk.
 
Revenues are recognized on the percentage-of-completion method, measured by the ratio of costs incurred up to a given date to estimated total costs for each contract. This cost to cost measure is used because management considers it to be the best available measure of progress on these contracts. Contract costs include all direct material, labor, subcontract and other costs and those indirect costs related to contract performance, such as indirect salaries and wages, equipment repairs and depreciation, insurance and payroll taxes. Administrative and general expenses are charged to expense as incurred. Provisions for estimated losses on uncompleted contracts are made in the period in which such losses are determined. Changes in job performance, job conditions and estimated profitability, including those changes arising from contract penalty provisions and final contract settlements may result in revisions to costs and income and are recognized in the period in which the revisions are determined.
 
Changes in estimated revenues and gross margin during the year ended December 31, 2014 resulted in a net charge of $9.1 million included in operating loss, or $0.50 per diluted share attributable to Sterling common stockholders, included in net loss attributable to Sterling common stockholders. Changes in estimated revenues and gross margin during the year ended December 31, 2013 resulted in a net charge of $57.6 million included in operating loss, or $3.46 per diluted share attributable to Sterling common stockholders, included in net loss attributable to Sterling common stockholders. Changes in estimated revenues and gross margin during the year ended December 31, 2012 resulted in a net charge of $4.9 million included in operating loss and a $5.3 million after-tax charge, or $0.32 per diluted share attributable to Sterling common stockholders, included in net loss attributable to Sterling common stockholders.
 
Change orders are modifications of an original contract that effectively change the existing provisions of the contract without adding new scope or terms. Change orders may include changes in specifications or designs, manner of performance, facilities, equipment, materials, sites and period of completion of the work. Either we or our customers may initiate change orders.
 
The Company considers unapproved change orders to be contract variations for which we have customer approval for a change of scope but a price change associated with the scope change has not yet been agreed upon. Costs associated with unapproved change orders are included in the estimated cost to complete the contracts and are treated as project costs as incurred. The Company recognizes revenue equal to costs incurred on unapproved change orders when realization of price approval is probable. Unapproved change orders involve the use of estimates, and it is reasonably possible that revisions to the estimated costs and recoverable amounts may be required in future reporting periods to reflect changes in estimates or final agreements with customers. Change orders that are unapproved as to both price and scope are evaluated as claims.
 
The Company considers claims to be amounts in excess of agreed contract prices that we seek to collect from our customers or others for customer-caused delays, errors in specifications and designs, contract terminations, change orders that are either in dispute or are unapproved as to both scope and price, or other causes of unanticipated additional contract costs. Revenue from claims is recognized when an agreement is reached with customers as to the value of the claims, which in some instances may not occur until after completion of work under the contract. Costs associated with claims are included in the estimated costs to complete the contracts and are treated as project costs when incurred.
 
There was $3.5 million in costs and estimated earnings in excess of billings at December 31, 2014 and no costs and estimated earnings in excess of billing at December 31, 2013, for contract change orders not approved by the customer. In addition, the Company has not recorded revenues related to claims during the years ended December 31, 2014, 2013 and 2012.
 
Our contracts generally take 12 to 36 months to complete. The Company generally provides a one to two-year warranty for workmanship under its contracts when completed. Warranty claims historically have been insignificant.
 
The asset, “Costs and estimated earnings in excess of billings on uncompleted contracts” represents revenues recognized in excess of amounts billed on these contracts and will be billed at a later date, usually due to contract terms. In addition, revenue associated with unapproved change orders is also included when realization is probable and amounts can be reliably determined. The liability, “Billings in excess of costs and estimated earnings on uncompleted contracts” represents billings in excess of revenues recognized on these contracts.
 
 
F9

 
Reclassification
 
A reclassification has been made to historical financial data on our consolidated financial statements to conform to our current year presentation. The caption, “Gains on sale of securities” has been modified to exclude “other” items. The “other” items included gains from insurance proceeds and miscellaneous other income and expense. Therefore, these amounts have been reclassified into “Other operating income, net” on the consolidated statement of operations to improve transparency.
 
Financial Instruments
 
The fair value of financial instruments is the amount at which the instrument could be exchanged in a current transaction between willing parties. The Company’s financial instruments are cash and cash equivalents, short-term investments, short-term and long-term contracts receivable, derivatives, accounts payable, mortgage and notes payable, a credit facility with Comerica Bank (“Credit Facility”), the buy/sell agreement related to certain noncontrolling owners’ interests in subsidiaries and an earn-out liability related to the acquisition of J. Banicki Construction, Inc. (“JBC”). The recorded values of cash and cash equivalents, short-term investments, short-term contracts receivable and accounts payable approximate their fair values based on their short-term nature. The recorded value of long-term contracts receivable is based on the amount of future cash flows discounted using the creditor’s borrowing rate and such recorded value approximates fair value. The recorded value of the Credit Facility debt approximates its fair value, as interest approximates market rates. Refer to Note 9 regarding the fair value of derivatives and Note 2 regarding the fair value of the buy/sell option and the earn-out liability along with the current amendments. The Company had one mortgage outstanding at December 31, 2014 and December 31, 2013 with a remaining balance of $0.1 million and $0.2 million, respectively. The mortgage was accruing interest at 3.5% at both December 31, 2014 and December 31, 2013 and contains pre-payment penalties. At December 31, 2014 and December 31, 2013 the fair value of the mortgage approximated its book value. The Company also has long-term notes payable of $3.3 million related to machinery and equipment purchased which have payment terms ranging from 3 to 5 years and associated interest rates ranging from 3.12% to 6.29%. The fair value of the notes payable approximates their book value. The Company does not have any off-balance sheet financial instruments other than operating leases (Refer to Note 14).
 
In order to assess the fair value of the Company’s financial instruments, the Company uses the fair value hierarchy established by GAAP which prioritizes the inputs used in valuation techniques into the following three levels:
 
Level 1 Inputs – Based upon quoted prices for identical assets in active markets that the Company has the ability to access at the measurement date.
 
Level 2 Inputs – Based upon quoted prices (other than Level 1) in active markets for similar assets, quoted prices for identical or similar assets in markets that are not active, inputs other than quoted prices that are observable for the asset such as interest rates, yield curves, volatilities and default rates and inputs that are derived principally from or corroborated by observable market data.
 
Level 3 Inputs – Based on unobservable inputs reflecting the Company’s own assumptions about the assumptions that market participants would use in pricing the asset based on the best information available.
 
For each financial instrument, the Company uses the highest priority level input that is available in order to appropriately value that particular instrument. In certain instances, Level 1 inputs are not available and the Company must use Level 2 or Level 3 inputs. In these cases, the Company provides a description of the valuation techniques used and the inputs used in the fair value measurement.
 
Contracts Receivable
 
Contracts receivable are generally based on amounts billed to the customer. At December 31, 2014 and 2013, contracts receivable included $16.4 million and $18.3 million of retainage, respectively, discussed below, which is being withheld by customers until completion of the contracts, and at December 31, 2014, and 2013, there were no unbilled receivables on contracts completed or substantially complete at that date. All contracts receivable include only balances approved for payment by the customer.
 
Many of the contracts under which the Company performs work contain retainage provisions. Retainage refers to that portion of billings made by the Company but held for payment by the customer pending satisfactory completion of the project. Unless reserved, the Company assumes that all amounts retained by customers under such provisions are fully collectible. Retainage on active contracts is classified as a current asset regardless of the term of the contract and is generally collected within one year of the completion of a contract.
 
There are certain contracts that are completed in advance of full payment. When the receivable will not be collected within our normal operating cycle, we consider it a long-term contract receivable and it is recorded in “Other assets, net” in our balance sheet. At December 31, 2014 and 2013, there was $5.0 million and $7.8 million recorded, respectively. We consider the credit quality of the borrower to assess the appropriate discount rate to apply and continuously monitor the borrower’s credit quality. Interest income related to this receivable was $0.4 million, $0.3 million and $0.1 million for the years ended December 31, 2014, 2013 and 2012, respectively.
 
 
F10

 
Contracts receivable are written off based on individual credit evaluation and specific circumstances of the customer, when such treatment is warranted. There was no bad debt expense recorded in 2014 or 2012. In 2013, the Company wrote off $1.8 million of contracts receivable to bad debt expense which was recorded in “Other operating income, net.” During 2014, we recovered $1.0 million of this $1.8 million.
 
Based upon a review of outstanding contracts receivable, historical collection information and existing economic conditions, management has determined that all contracts receivable at December 31, 2014 are fully collectible, and accordingly, no allowance for doubtful accounts against contracts receivable is necessary.
 
As is customary, we have agreed to indemnify our bonding company for all losses incurred by it in connection with bonds that are issued, and we have granted our bonding company a security interest in certain assets, including accounts receivable, as collateral for such obligation.
 
Inventories
 
The Company’s inventories are stated at the lower of cost or market as determined by the average cost method. Inventories at December 31, 2014 and 2013 were $7.4 million and $6.2 million, respectively. Inventories consist primarily of concrete, aggregate and millings which are primarily expected to be utilized on construction projects in the future. A small portion is sold to third parties. The cost of inventory includes labor, trucking and other equipment costs.
 
Property and Equipment
 
Property and equipment are stated at cost. Depreciation and amortization are computed using the straight-line method. The estimated useful lives used for computing depreciation and amortizations are as follows:
 
Buildings (years)
 
39
   
Construction equipment (years)
5
-
15  
Land improvements (years)
5
-
15  
Office furniture and fixtures (years)
3
-
10  
Leasehold improvements (years or lease period, if shorter)
3
-
10  
Transportation equipment (years)
 
5
   
 
Depreciation expense was $18.2 million, $18.6 million and $19.0 million in 2014, 2013 and 2012, respectively.
 
Leases
 
We lease property and equipment in the ordinary course of our business. Our leases have varying terms. Some may include renewal options, escalation clauses, restrictions, penalties or other obligations that we consider in determining minimum lease payments. The leases are classified as either operating leases or capital leases, as appropriate.
 
Equipment under Capital Leases
 
The Company’s policy is to account for capital leases, which transfer substantially all the benefits and risks incident to the ownership of the leased property to the Company, as the acquisition of an asset and the incurrence of an obligation. Under this method of accounting, the recorded value of the leased asset is amortized principally using the straight-line method over its estimated useful life and the obligation, including interest thereon, is reduced through payments over the life of the lease. Depreciation expense on equipment subject to capital leases and the related accumulated depreciation is included with that of owned equipment. The Company had no capital leases during the years ended December 31, 2014, 2013 and 2012.
 
 Deferred Loan Costs
 
Deferred loan costs represent loan origination fees paid to the lender and related professional fees such as legal fees related to drafting of loan agreements. During 2014, the Company capitalized an additional $0.2 million in loan fees paid to our lender as part of the Fourth Amendment, discussed further in Note 11. These capitalized fees are amortized over the term of the loan. Unamortized costs were $0.2 million at December 31, 2014 and 2013 and are attributable to the Credit Facility (Refer to Note 11). Loan cost amortization expense for the years ended December 31, 2014 and 2013 was $0.2 million and $0.1 million, respectively, and were minimal for 2012.
 
 
F11

 
Goodwill and Intangibles
 
Goodwill represents the excess of the cost of companies acquired over the fair value of their net assets at the dates of acquisition. GAAP requires that: (1) goodwill and indefinite lived intangible assets not be amortized, (2) goodwill is to be tested for impairment at least annually at the reporting unit level and (3) intangible assets deemed to have an indefinite life are to be tested for impairment at least annually by comparing the fair value of these assets with their recorded amounts. Refer to Note 8 for our disclosure regarding goodwill impairment testing.
 
Evaluating Impairment of Long-Lived Assets
 
When events or changes in circumstances indicate that long-lived assets may be impaired, an evaluation is performed. The evaluation would be based on estimated undiscounted cash flow associated with the assets as compared to the asset’s carrying amount to determine if a write-down to fair value is required. There was no impairment in 2014, 2013 and 2012, and management believes that there are no events or changes in circumstances which have indicated that long-lived assets may be impaired.
 
Segment reporting
 
We operate in one segment and have only one reportable segment and one reporting unit component, which is heavy civil construction. In making this determination, the Company considered the discrete financial information used by our Chief Operating Decision Maker (“CODM”). Based on this approach, the Company noted that the CODM organizes, evaluates and manages the financial information around each heavy civil construction project when making operating decisions and assessing the Company’s overall performance. The service provided by the Company, in all instances of our construction projects, is heavy civil construction. Furthermore, we considered that each heavy civil construction project has similar characteristics, includes similar services, has similar types of customers and is subject to similar economic and regulatory environments which would allow aggregation of individual operating segments into one reportable segment if multiple operating segments existed.
 
The Company noted that even if our local offices were to be considered separate components of our heavy civil construction operating segment, those components could be aggregated into a single reporting unit for purposes of testing goodwill for impairment under Accounting Standards Codification 280 and EITF D-101 because our local offices all have similar economic characteristics and are similar in all of the following areas:
 
·
The nature of the products and services — each of our local offices perform similar construction projects — they build, reconstruct and repair roads, highways, bridges, light rail and water, waste water and storm drainage systems.
·
The nature of the production processes — our heavy civil construction services rendered in the construction process for each of our construction projects performed by each local office is the same — they excavate dirt, remove existing pavement and pipe, lay aggregate or concrete pavement, pipe and rail and build bridges and similar large structures in order to complete our projects.
·
The type or class of customer for products and services — substantially all of our customers are federal and state departments of transportation, cities, counties, and regional water, rail and toll-road authorities. A substantial portion of the funding for the state departments of transportation to finance the projects we construct is furnished by the federal government.
·
The methods used to distribute products or provide services — the heavy civil construction services rendered on our projects are performed primarily with our own field work crews (laborers, equipment operators and supervisors) and equipment (backhoes, loaders, dozers, graders, cranes, pug mills, crushers, and concrete and asphalt plants).
·
The nature of the regulatory environment — we perform substantially all of our projects for federal, state and municipal governmental agencies, and all of the projects that we perform are subject to substantially similar regulation under U.S. and state department of transportation rules, including prevailing wage and hour laws; codes established by the federal government and municipalities regarding water and waste water systems installation; and laws and regulations relating to workplace safety and worker health of the U.S. Occupational Safety and Health Administration and to the employment of immigrants of the U.S. Department of Homeland Security.
 
While profit margin objectives included in contract bids have some variability from contract to contract, our profit margin objectives are not differentiated by our CODM or our office management based on local office location. Instead, the projects undertaken by each local office are primarily competitively-bid, fixed unit or negotiated lump sum price contracts, all of which are bid based on achieving gross margin objectives that reflect the relevant skills required, the contract size and duration, the availability of our personnel and equipment, the makeup and level of our existing backlog, our competitive advantages and disadvantages, prior experience, the contracting agency or customer, the source of contract funding, anticipated start and completion dates, construction risks, penalties or incentives and general economic conditions.
 
 
F12

 
Federal and State Income Taxes
 
We determine deferred income tax assets and liabilities using the balance sheet method. Under this method, the net deferred tax asset or liability is determined based on the tax effects of the temporary differences between the book and tax bases of the various balance sheet assets and liabilities and gives current recognition to changes in tax rates and laws. Valuation allowances are established when necessary to reduce deferred tax assets to the amount expected to be realized. We recognize the financial statement benefit of a tax position only after determining that the relevant tax authority would more likely than not sustain the position following an audit. For tax positions meeting the more-likely-than-not threshold, the amount recognized in the financial statements is the largest benefit that has a greater than 50 percent likelihood of being realized upon ultimate settlement with the relevant tax authority. Refer to Note 12 for further information regarding our federal and state income taxes.
 
Stock-Based Compensation
 
The Company’s stock-based incentive plan is administered by the Compensation Committee of the Board of Directors. The Compensation Committee may reward employees and non-employees with various types of awards including but not limited to warrants, stock options, common stock, and unvested common stock (or restricted stock) vesting on service or performance criteria. The Company recognizes expense based on the grant-date fair value of the award and amortizes the award based on accelerated or straight line methods. Awards based on performance vesting are subsequently remeasured at each reporting date through the settlement date.
 
Upon the vesting of unvested common stock the Company may withhold shares, based on the employee’s election, in order to satisfy federal tax withholdings. The shares held by the Company are considered constructively retired and are retired shortly after withholding. The Company then remits the withholding taxes required. Refer to Note 16 for further information regarding the stock-based incentive plans.
 
Recent Accounting Pronouncements
 
In August 2014, the Financial Accounting Standards Board (“FASB”) issued ASU 2014-14, “Presentation of Financial Statement – Going Concern.” The guidance, which is effective for annual reporting periods ending after December 15, 2016 and interim periods within annual periods beginning after December 15, 2016, requires management to evaluate whether there is substantial doubt about the entity’s ability to continue as a going concern and to provide related footnote disclosures. Early adoption is permitted. Although early adoption is permitted, the Company expects to adopt this guidance as required and does not expect a material impact to our financial statements.
 
In May 2014, the FASB issued ASU 2014-09, “Revenue from Contracts with Customers.” The guidance, which is effective for annual reporting periods beginning after December 15, 2016, defines the steps to recognize revenue for entities that have contracts with customers. Early adoption is not permitted. The Company is currently evaluating the impact to the Company’s financial statements.
 
In July 2013, the FASB issued ASU 2013-11, "Presentation of an Unrecognized Tax Benefit When a Net Operating Loss Carryforward, a Similar Tax Loss, or a Tax Credit Carryforward Exists." This ASU clarifies the financial statement presentation of unrecognized tax benefits in certain circumstances. ASU 2013-11 is effective for interim and annual reporting periods beginning after December 15, 2013 and should be applied prospectively to all unrecognized tax benefits that exist at the effective date. The adoption of ASU 2013-11 did not have a material impact on the Company's consolidated financial statements.
 
In February 2013, the FASB issued ASU 2013-04, "Obligations Resulting from Joint and Several Liability Arrangements for Which the Total Amount of the Obligation Is Fixed at the Reporting Date," which addresses the recognition, measurement and disclosure of certain obligations including debt arrangements, other contractual obligations and settled litigation and judicial rulings. ASU 2013-04 is effective for interim and annual reporting periods beginning after December 15, 2013. The adoption of ASU 2013-04 did not have a material impact on the Company's consolidated financial statements.
 
2.  
Acquisitions and Subsidiaries and Joint Ventures with Noncontrolling Owners’ Interests
 
RHB
 
In January 2012, RHB, a wholly owned subsidiary, assumed six construction contracts with $25.0 million of unearned revenues from Aggregate Industries―SWR, Inc. (“AI”), an unrelated third party. In addition, Aggregate South West Holdings, LLC (“ASWH”) and RHB Properties, LLC (“RHBP”), newly formed entities owned by Richard Buenting, the President and Chief Executive Officer of RHB, acquired construction related machinery and equipment and land with quarries from AI. AI entered into a two-year non-compete agreement with respect to Utah, Idaho and Montana as well as certain areas of Nevada. On April 27, 2012, RHB merged with ASWH and acquired RHBP. In exchange, RHB granted Mr. Buenting a 50% member interest in RHB. These transactions allowed RHB to expand its operations in Nevada.
 
 
F13

 
These transactions were accounted for as a business combination. In December 2012, the Company finalized its valuation of the assets acquired, the membership interest granted and the tax related impact of the transaction. The purchase price for the transaction was $9.8 million for the assets acquired net of a contract liability. In addition, the Company recorded a credit of $233,000 to “Additional paid in capital” resulting from the excess of the post-merger member capital over the Company’s book value of the 50% investment in RHB issued to Mr. Buenting. As a result of the merger, an additional difference between the Company’s tax basis related to RHB and its book basis was created. Accordingly, the Company recorded an additional deferred tax liability of $360,000 with an offset to goodwill.
 
Revenues and earnings related to the contracts assumed and the acquired companies for 2012 were $26.1 million and $152,000, respectively. In connection with this transaction, AI did not agree to provide us with historical information related to the earnings from the acquired operations except for information related to the specific contracts being assumed. Furthermore, we determined that such information was not needed in order to evaluate the transaction based on our knowledge of the assets acquired and the Nevada road and highway construction market.
 
The Company also agreed with Mr. Buenting to amend and restate the operating and management agreements for RHB. The amended agreements provide that the Company is the Manager of RHB and retains full, exclusive and complete power, authority and discretion to manage, supervise, operate and control RHB; therefore, the Company consolidates RHB with its other subsidiaries. Under the amendments, the Company will provide RHB with access to a $5 million line of credit. The Company also entered into a buy/sell and management agreement with Mr. Buenting. Under this agreement, the Company or Mr. Buenting may annually elect to make offers to buy the other owner’s 50% interest in RHB and sell their 50% interest in RHB at a price which they specify. Upon receipt of the offers, the other owner must elect either to sell their interest or purchase the interest from the owner making the offers. The agreement also requires that the Company acquire Mr. Buenting’s interest in the event of his termination without cause, death, or disability. To the extent that the redemption value under the buy/sell and management agreement exceeds the initial valuation of Mr. Buenting’s noncontrolling interest, the Company records a charge to retained earnings, or in the absence of retained earnings, additional paid-in capital (“APIC”). Any related benefit as a result of a lower valuation of Mr. Buenting’s noncontrolling interest compared to previous valuations shall be offset to retained earnings up to the amounts previously charged to retained earnings. The calculation used in the buy/sell and management agreement is the higher of the trailing twelve months of earnings before interest, taxes and depreciation and amortization (“EBITDA”) times a multiple of 4.5 or the orderly liquidation value of RHB. The valuation of the orderly liquidation value is classified as a Level 2 fair value measurement. These values have been updated based on recent sales and dispositions of assets and liabilities to obtain a current estimate of the orderly liquidation value. Based on the Company’s calculation on December 31, 2013, the trailing twelve months EBITDA times the multiple of 4.5 provided the higher result of the two methods. As such, the total charge resulted in a net pre-tax charge of $1.9 million and $2.5 million, for the periods ending December 31, 2013 and 2012, respectively.
 
On December 30, 2013, the Company and Mr. Buenting revised the Second Amended and Restated Operating Agreement entered into on April 27, 2012 and their Management Agreement entered into on February 1, 2012. The Third Amended and Restated Operating Agreement and the amended Management Agreement eliminated the buy/sell option and instead included the obligation for the Company to purchase Mr. Buenting’s interest upon his death or permanent disability for $20 million or $18 million, respectively. In the event of Mr. Buenting’s death or permanent disability, his estate representative, trustee or designee shall become the selling representative and sell his 50% interest to the Company. In order to fund the purchase of Mr. Buenting’s interest, the Company has purchased term life insurance with a payout of $20 million in the event of Mr. Buenting death. The Company will be the beneficiary and will also pay the premiums related to this life insurance contract. The life insurance proceeds of $20 million shall be used as full payment for Mr. Buenting’s interest in the occurrence of his death. In the event of Mr. Buenting’s permanent disability, the $18 million payment will be made by using the Company’s available cash on hand, and/or to the extent necessary, the Company’s line of credit. No other transfer of Member’s interest is permitted other than to the selling representative in the event of Mr. Buenting’s death or permanent disability. In the event that Mr. Buenting resigns or is terminated without cause (i.e., termination other than through permanent disability or death) RHB shall be dissolved unless both members agree otherwise. The amended agreements were entered into in order to eliminate the earnings per share volatility caused by the buy/sell option.
 
 
F14

 
The amended agreements resulted in an obligation that the Company is certain to incur, either through Mr. Buenting’s permanent disability or death for Mr. Buenting’s 50% members interest; therefore, the Company has classified the noncontrolling interest as mandatorily redeemable and has recorded a liability in “Member’s interest subject to mandatory redemption and undistributed earnings” on the consolidated balance sheet. The liability consists of the following (in thousands):
 
   
Years Ended December 31,
 
   
2014
   
2013
 
Member’s interest subject to mandatory redemption
  $ 20,000     $ 20,000  
Undistributed earnings attributable to this interest
    6,079       3,989  
Earnings distributed
    (3,200 )     -  
Total liability
  $ 22,879     $ 23,989  
 
Undistributed earnings increased by $2.1 million for the year ended December 31, 2014, and were included in “Other operating income, net” on the Company’s consolidated statement of operations. Distributions for the year ended December 31, 2014 were $3.2 million.
 
At September 30, 2013, the total Obligation for noncontrolling owners’ interests in subsidiaries and joint ventures was $17.8 million which included $14.1 million as the fair value in the noncontrolling interest and $3.7 million in undistributed earnings. During the fourth quarter of 2013, the Company made a final entry of $5.9 million to adjust the member’s interest to its final payout value of $20.0 million. The adjustment was made to APIC as there was a retained deficit on the Company’s consolidated balance sheet. Undistributed earnings increased by $0.3 million during the fourth quarter and there was no payout of undistributed earnings.
 
RHB Inc.
 
On June 20, 2014, the Company sold to Mr. Buenting a 50% interest in RHB Inc. RHB Inc. is currently an ancillary company that provides certain services for RHB LLC. RHB Inc. is run as a cost center with a financial goal to break-even, and has an immaterial amount of assets. The purchase price and the accounting effects of the total transaction were immaterial to the Company.
 
JBC
 
In connection with the August 1, 2011, acquisition of J. Banicki Construction, Inc. (“JBC”) by Ralph L. Wadsworth Construction Company, LLC (“RLW”), RLW agreed to additional purchase price payments of up to $5 million to be paid over a five-year period. The additional purchase price is in the form of an earn-out is classified as a Level 3 fair value measurement. In making this valuation, the unobservable input consisted of forecasted EBITDA for the periods after the period being reported on through July 31, 2016. The additional purchase price is calculated generally as 50% of the amount by which EBITDA exceeds $2.0 million for each of the calendar years 2011 through 2015 and $1.2 million for the seven months ended July 31, 2016.
 
On January 23, 2014, RLW, the former owner of JBC and the Company agreed to amend the above-mentioned earn-out agreement in order to reduce the Company’s currently recorded liability while providing the former owner, who at the time was the chief executive officer of JBC, a greater incentive to meet earnings benchmarks. The amendment resulted in a reduction of $0.6 million in the Company’s earn-out liability, thereby reducing the total earn-out liability to $1.4 million on December 31, 2013. As part of the amendment, a payment of $0.8 million was made during the first quarter of 2014. The amendment increases the total available earn-out from $5.0 million to $10.0 million if certain EBITDA benchmarks are met. The amendment extends the earn-out period through December 31, 2017 and reduces the benchmark EBITDA for 2014 and 2015 to $1.5 million and increases it to $2.0 million in 2016 and 2017. The yearly excess forecasted EBITDA in our calculation ranged from 0% to 22.4% of the minimum EBITDA threshold for the years 2015 through 2017. The discounted present value of the additional purchase price was estimated to be $2.4 million as of August 1, 2011, the acquisition date, and $0.3 million as of December 31, 2014. The undiscounted earn-out liability as of December 31, 2014 is estimated at $0.3 million and could increase by $9.0 million if EBITDA during the earn-out period increases $18.0 million or more and could decrease by the full amount of the liability for the year if EBITDA does not exceed the minimum threshold for that year. Each year is considered a discrete earnings period and future losses by JBC, if any, would not reduce the Company’s liability in years in which JBC has exceeded its earnings benchmark. Any significant increase or decrease in actual EBITDA compared to the forecasted amounts would result in a significantly higher or lower fair value measurement of the additional purchase price. This liability is included in other long-term liabilities on the accompanying consolidated balance sheets. As part of recording the present value of this liability, the Company incurs accreted interest expense for the passage of time until the time of settlement. The Company incurred accreted interest expense of less than $0.1 million for the year ended December 31, 2013 and slightly over $0.1 million in the same period of 2012. As part of the amendment in 2014 and the fair value adjustment, the Company recorded interest income of $0.3 million for the year ended December 31, 2014.
 
 
F15

 
RLW
 
In connection with the December 3, 2009 acquisition of RLW, the noncontrolling interest owners of RLW, who are related and also its executive management, had the right to require the Company to buy their remaining 20.0% interest in RLW in 2013, and concurrently, the Company had the right to require those owners to sell their 20.0% interest to the Company by July 2013 (the “RLW put/call”). The purchase price in each case was 20% of the product of the simple average of RLW’s EBITDA for the calendar years 2010, 2011 and 2012 times a multiple of a minimum of 4 and a maximum of 4.5.
 
Annual interest was accreted for the RLW put/call obligation based on the Company’s borrowing rate under its Credit Facility plus two percent. Such accretion amounted to $1.0 million for the year ended December 31, 2012 and was recorded in “Interest expense” in the accompanying consolidated statement of operations. In addition, based on the estimated average of RLW’s EBITDA for the calendar years 2010, 2011 and 2012 and the expected multiple, the estimated fair value of the RLW put/call was increased by approximately $3.8 million for the year ended December 31, 2012 and this change, net of tax of $1.3 million was reported as a charge to retained earnings.
 
Under the agreement with the noncontrolling interest owners of RLW, the Company purchased the 20% interest in RLW on December 31, 2012 subject to a final determination of RLW’s EBITDA for the period from January 1, 2010 through December 31, 2012. A payment of $23.1 million was made on December 31, 2012, and the Company made a final payment of $509,000 in April 2013.  In addition, $2.3 million of undistributed earnings was also paid in April 2013.
 
In 2012, the Company agreed to amend RLW’s operating agreement effective January 1, 2012 to provide that any goodwill impairment, including the 2011 fourth quarter goodwill impairment, is not to be allocated to RLW for the purpose of calculating the distributions to be made to the RLW noncontrolling interest owners. This amendment resulted in an increase in the net income attributable to RLW’s noncontrolling interests of $6.7 million during the year ended December 31, 2012.  This increase is included in “Noncontrolling owners’ interests in earnings of subsidiaries and joint ventures” in the accompanying consolidated statement of operations with an increase in the “Current obligation for noncontrolling owners’ interests in subsidiaries and joint ventures” in the consolidated balance sheet.  This increase had a related tax impacted of $2.4 million which increased the tax benefit for the period.
 
Changes in noncontrolling interests
 
The following table summarizes the changes in the noncontrolling owners’ interests in subsidiaries and consolidated joint ventures for the years ended December 31, 2012 through 2014 (amounts in thousands):
 
   
Years Ended December 31,
 
   
2014
   
2013
   
2012
 
Balance, beginning of period
  $ 4,097     $ 20,046     $ 18,375  
Net income attributable to noncontrolling interest included in liabilities
    -       2,024       16,941  
Net income attributable to noncontrolling interest included in equity
    4,556       1,879       1,068  
Accretion of interest on puts
    -       -       993  
Change in fair value of RLW put/call
    -       (59 )     3,797  
Change in fair value of RHB put/call
    -       1,875       2,473  
Change due to the RHB amendment
    -       (18,103 )     -  
Issuance of noncontrolling interest in RHB in exchange for net assets of acquired companies
    -       -       9,767  
Distributions to noncontrolling interests owners
    (1,191 )     (3,056 )     (10,185 )
Acquisition of RLW noncontrolling interest
    -       (509 )     (23,144 )
Other
    -       -       (39 )
Balance, end of period
  $ 7,462     $ 4,097     $ 20,046  
 
Noncontrolling owners’ interest in earnings of subsidiaries and joint ventures for the year ended December 31, 2014 shown in the accompanying consolidated statement of operations is $4.6 million, which the Company includes in ”Equity”, “Noncontrolling interests” in the accompanying consolidated balance sheet. There were distributions of $1.2 million to certain noncontrolling interest members during the year ended December 31, 2014.
 
 
F16

 
 
Noncontrolling owners’ interest in earnings of subsidiaries and joint ventures for the year ended December 31, 2013 shown in the accompanying consolidated statement of operations of $3.9 million, includes income of $2.0 million attributable to noncontrolling interest owners, which the Company includes in liabilities and $1.9 million which the Company includes in equity. Of the $2.0 million included in liabilities, less than $0.1 million of net loss was reflected in “Current obligations for noncontrolling owners’ interests in subsidiaries and joint ventures,” and $2.1 million of net income has been reclassified from “Obligations for noncontrolling owners’ interests in subsidiaries and joint ventures,” leaving the Company with a zero balance in this account, to “Member’s interest subject to mandatory redemption” in the accompanying consolidated balance sheet. The remaining $1.9 million was attributable to noncontrolling interest owners which the Company includes in equity and was reflected in equity in “Noncontrolling interests” in the accompanying consolidated balance sheet.
  
Noncontrolling owners’ interest in earnings of subsidiaries and joint ventures for the year ended December 31, 2012 shown in the accompanying consolidated statement of operations of $18.0 million includes $15.0 million attributable to the RLW noncontrolling interest owners, which was reflected in “Current obligation for noncontrolling owners’ interests in subsidiaries and joint ventures,” $1.9 million attributable to RHB noncontrolling interest owners, which was reflected in “Obligation for noncontrolling owners’ interest in subsidiaries and joint ventures” and income of $1.1 million attributable to Myers’ noncontrolling interest owners which was reflected in equity in “Noncontrolling interests” in the accompanying consolidated balance sheet.
 
3.  
Variable Interest Entities
 
Under GAAP, the Company must determine whether each entity, including joint ventures in which it participates, is a variable interest entity (“VIE”). This determination focuses on identifying which owner or joint venture partner, if any, has the power to direct the activities of the entity and the obligation to absorb losses of the entity or the right to receive benefits from the entity disproportionate to its interest in the entity, which could have the effect of requiring us to consolidate the entity in which we have a noncontrolling variable interest. Where the Company has determined that it is appropriate to consolidate a VIE which it owns a 50% or less interest, the equity held by the remaining owners and their portions of net income (loss) are reflected in the balance sheet line item “Noncontrolling interests” in “Equity” and the statement of operations line item “Noncontrolling owners’ interests in earnings of subsidiaries and joint ventures.”
 
On August 1, 2011, the Company purchased a 50% limited partner interest in Myers. Myers is a construction limited partnership located in California and was acquired in order to expand the geographic scope of the Company’s operations into California. The Company has determined that Myers is a VIE for which the Company is the primary beneficiary and has consolidated Myers into these financial statements.
 
The determination that Myers is a VIE and that the Company is the primary beneficiary is primarily due to the following factors. The partnership agreement requires that Sterling provide a $3 million line of credit to the limited partnership. In addition the partnership is relying on the Company’s surety bonding capacity in order to bid and perform large construction jobs resulting in the Company having joint and several liability for completion of such jobs, and the Company will provide management to the partnership to oversee bidding and management of larger projects. Although the Company will receive 50% of the income from the partnership, it may suffer more than 50% of any losses as a result of its obligation to provide the $3 million line of credit and its obligations under the surety bonds. Because the Company exercises primary control over activities of the partnership and it is exposed to the majority of potential losses of the partnership, the Company consolidated Myers within the Company’s financial statements from August 1, 2011, the date of acquisition.
 
 
F17

 
The financial information of Myers which is reflected in our consolidated balance sheets and statements of operations is as follows (amounts in thousands):
 
   
As of December 31,
 
   
2014
   
2013
 
Assets:
           
Current assets:
           
Cash and cash equivalents
  $ 148     $ 566  
Contracts receivable, including retainage
    21,327       6,475  
Other current assets
    7,656       7,964  
Total current assets
    29,131       15,005  
Property and equipment, net
    9,303       6,869  
Other assets, net
    -       5  
Goodwill
    1,501       1,501  
Total assets
  $ 39,935     $ 23,380  
Liabilities:
               
Current liabilities:
               
Accounts payable
  $ 15,795     $ 8,361  
Other current liabilities
    9,000       7,080  
Total current liabilities
    24,795       15,441  
Long-term liabilities:
               
Other long-term liabilities
    16       137  
Total liabilities
  $ 24,811     $ 15,578  
 
   
Year Ended December 31,
 
   
2014
   
2013
   
2012
 
Revenues
  $ 144,837     $ 82,421     $ 84,877  
Operating income
    9,319       3,764       2,152  
Net income attributable to Sterling common stockholders
    4,657       1,879       694  
 
4.  
Cash and Cash Equivalents and Short-term Investments
 
The Company considers all highly liquid investments with original or remaining maturities of three months or less at the time of purchase to be cash equivalents. Cash and cash equivalents include cash balances held by our wholly-owned subsidiaries as well as the Company’s VIE.
 
The Company holds cash on deposit in U.S. banks, at times, in excess of federally insured limits. Management does not believe that the risk associated with keeping cash deposits in excess of federal deposit insurance limits represents a material risk.
 
At December 31, 2014 and 2013, the Company had no short-term investments.
 
At December 31, 2014, there were no cash and cash equivalents belonging to majority-owned joint ventures that are consolidated in these financial statements. At December 31, 2013, cash and cash equivalents included $0.4 million belonging to majority-owned joint ventures that are consolidated in these financial statements which generally cannot be used for purposes outside such joint ventures.
 
Gains and losses realized on short-term investment securities are included in “Gains on sale of securities” in the accompanying statements of operations. Unrealized gains (losses) on short-term investments are included in accumulated other comprehensive income in stockholders’ equity, net of tax, as the gains and losses may be temporary. For the year ended December 31, 2013 and 2012, total proceeds from sales of short-term investments were $49.9 million and $26.7 million, respectively, with gross realized gains of $0.7 million and $0.8 million, respectively, and gross realized losses of $0.6 million and $0, respectively. Accumulated other comprehensive income at December 31, 2013 included no unrealized gains on short-term investments and $1.1 million at December 31, 2012. Upon the sale of short-term investments, the cost basis used to determine the gain or loss based on the specific identification of the security sold. All items included in accumulated other comprehensive income are at the corporate level, and no portion is attributable to noncontrolling interests.
 
 
F18

 
At each reporting date, the Company performs separate evaluations of impaired debt and equity securities to determine if the unrealized losses are other-than-temporary. The evaluations include a number of factors, including but not limited to, the length of time and extent to which the fair value has been less than cost, the financial condition and near-term prospects of the issuer, and management’s ability and intent to hold the securities until fair value recovers. The assessment of the ability and intent to hold these securities to recovery focuses primarily on liquidity needs and securities portfolio objectives. At December 31, 2014 and 2013, the Company had no short-term investments; thus no evaluation was required.
 
The Company earned interest income of $0.6 million and $1.5 million for the years ended December 31, 2013 and 2012, respectively, on its cash, cash equivalents and short-term investments. These amounts are recorded in “interest income” in the Company’s consolidated statement of operations.
 
5.  
Costs and Estimated Earnings and Billings on Uncompleted Contracts
 
Billing practices for our contracts are governed by the contract terms of each project based on progress toward completion approved by the owner, achievement of milestones or pre-agreed schedules. Billings do not necessarily correlate with revenue recognized under the percentage-of-completion method of accounting. The current liability, “Billings in excess of costs and estimated earnings on uncompleted contracts,” represents billings in excess of revenues recognized. The current asset, “Costs and estimated earnings in excess of billings on uncompleted contracts,” represents revenues recognized in excess of amounts billed to the customer, which are usually billed during normal billing processes following achievement of contractual requirements. In addition, revenue associated with unapproved change orders is also included when realization is probable and amounts can be reliably determined.
 
The two tables below set forth the costs incurred and earnings accrued on uncompleted contracts (revenues) compared with the billings on those contracts through December 31, 2014 and 2013 and reconcile the net excess billings to the amounts included in the consolidated balance sheets at those dates (amounts in thousands).
 
   
As of December 31,
 
   
2014
   
2013
 
Costs incurred and estimated earnings on uncompleted contracts
  $ 1,566,831     $ 1,334,322  
Billings on uncompleted contracts
    (1,559,077 )     (1,354,214 )
Excess of costs incurred and estimated earnings over billings (excess of billings over costs incurred and estimated earnings) on uncompleted contracts
  $ 7,754     $ (19,892 )
 
Included in the accompanying balance sheets under the following captions:
 
   
As of December 31,
 
   
2014
   
2013
 
Costs and estimated earnings in excess of billings on uncompleted contracts
  $ 33,403     $ 11,684  
Billings in excess of costs and estimated earnings on uncompleted contracts
    (25,649 )     (31,576 )
Net amount of costs and estimated earnings on uncompleted contracts above (below) billings
  $ 7,754     $ (19,892 )
 
Revenues recognized and billings on uncompleted contracts include cumulative amounts recognized as revenues and billings in prior years.
 
6.
Construction Joint Ventures
 
We participate in joint ventures with other large construction companies and other partners, typically for large, technically complex projects, including design-build projects, when it is desirable to share risk and resources in order to seek a competitive advantage or when the project is too large for us to obtain sufficient bonding. Joint venture partners typically provide independently prepared estimates, furnish employees and equipment, enhance bonding capacity and often also bring local knowledge and expertise. We select our joint venture partners based on our analysis of their construction and financial capabilities, expertise in the type of work to be performed and past working relationships with us, among other criteria.
 
We participate in various construction joint venture partnerships. Generally, each construction joint venture is formed to accomplish a specific project and is jointly controlled by the joint venture partners. The joint venture agreements typically provide that our interests in any profits and assets, and our respective share in any losses and liabilities that may result from the performance of the contract are limited to our stated percentage interest in the venture. We have no significant commitments beyond completion of the contract with the customer.
 
 
F19

 
Joint venture contracts with project owners typically impose joint and several liability on the joint venture partners. Although our agreements with our joint venture partners provide that each party will assume and pay its share of any losses resulting from a project, if one of our partners is unable to pay its share, we would be fully liable under our contract with the project owner. Circumstances that could lead to a loss under these guarantee arrangements include a partner’s inability to contribute additional funds to the venture in the event that the project incurs a loss or additional costs that we could incur should the partner fail to provide the services and resources toward project completion that had been committed to in the joint venture agreement. Historically, the Company has not incurred a liability related to the nonperformance of a joint venture partner.
 
Under a joint venture agreement, one partner is typically designated as the sponsor or manager. The sponsoring partner typically provides all administrative, accounting and most of the project management support for the project and generally receives a fee from the joint venture for these services. We have been designated as the sponsoring partner in certain of our current joint venture projects and are a non-sponsoring partner in others.
 
Under GAAP, the Company must determine whether each joint venture in which it participates is a variable interest entity. This determination focuses on identifying which joint venture partner, if any, has the power to direct the activities of a joint venture and the obligation to absorb losses of the joint venture or the right to receive benefits from the joint venture in excess of their ownership interests and could have the effect of requiring us to consolidate joint ventures in which we have a noncontrolling variable interest. At December 31, 2014, we had no participation in a joint venture where we had a material non-majority variable interest.
 
Where we are a noncontrolling venture partner, we account for our share of the operations of such construction joint ventures on a pro rata basis using proportionate consolidation on our consolidated statements of operations and as a single line item (“Receivables from and equity in construction joint ventures”) in the consolidated balance sheets. This method is an acceptable modification of the equity method of accounting which is a common practice in the construction industry. Combined financial amounts of joint ventures in which the Company has a noncontrolling interest and the Company’s share of such amounts which are included in the Company’s consolidated financial statements are shown below (amounts in thousands):
 
   
As of December 31,
 
   
2014
   
2013
 
Total combined:
           
Current assets
  $ 18,132     $ 51,329  
Less current liabilities
    (49,035 )     (64,531 )
Net assets
  $ (30,903 )   $ (13,202 )
Backlog
  $ 55,063     $ 101,014  
 
   
Years Ended December 31,
 
   
2014
   
2013
   
2012
 
Total combined:
                 
Revenues
  $ 51,015     $ 135,699     $ 438,756  
Income before tax
    3,606       (20,758 )     95,765  
Sterling’s noncontrolling interest:
                       
Share of revenues
  $ 20,243     $ 54,096     $ 82,519  
Share of income before tax
    2,111       (11,088 )     12,424  
 
   
As of December 31,
 
   
2014
   
2013
 
Sterling’s noncontrolling interest in backlog
  $ 15,889     $ 30,652  
Sterling’s receivables from and equity in construction joint ventures
    9,153       6,118  
 
Approximately $16 million of the Company’s backlog at December 31, 2014 was attributable to projects performed by joint ventures. The majority of this amount is attributable to the Company’s joint venture with Shimmick Construction Company, where the Company has a 30% interest.
 
The caption “Receivables from and equity in construction joint ventures,” includes undistributed earnings and receivables owed to the Company. Undistributed earnings are typically released to the joint venture partners after the customer accepts the project as completed and any warranty period, if any, has passed.
 
 
F20

 
7.  
Property and Equipment
 
Property and equipment are summarized as follows (amounts in thousands):
 
   
As of December 31,
 
   
2014
    2013  
Construction equipment
  $ 129,150     $ 127,199  
Transportation equipment
    18,205       19,132  
Buildings
    10,777       10,512  
Office equipment
    2,761       2,025  
Leasehold Improvement
    878       816  
Construction in progress
    387       -  
Land
    5,530       5,309  
Water rights
    200       200  
      167,888       165,193  
Less accumulated depreciation
    (80,790 )     (71,510 )
    $ 87,098     $ 93,683  
 
 
8.  
Goodwill
 
Goodwill represents the excess of the cost of companies acquired over the fair value of their net assets at the dates of acquisition. GAAP requires that goodwill not be amortized and that goodwill is to be tested for impairment at least annually at the reporting unit level. The Company tests for goodwill impairment on October 1st of each calendar year. There are two steps involved in the testing of goodwill, excluding a qualitative analysis. The first step compares the book value of the Company’s stock (stockholders’ equity or net assets) to the adjusted fair market value of those shares. If the adjusted fair value of the stock is greater than the calculated book value of the stock, goodwill is deemed not to be impaired and no further testing is required. If the adjusted fair value is less than the calculated book value, then step two of determining the fair value of net assets must be taken to determine the impairment amount.
 
To determine the fair value of the Company’s net assets, the Company used the weighted average of the following valuation techniques: market capitalization plus control premium (market) approach and a discounted cash flow (income) approach. The market approach includes level one fair value inputs, such as the Company’s stock price, at October 1, 2014, and level two fair value inputs, such as the control premiums based on prior year sales transactions of construction contractors and engineering services, similar sized transactions based on the Company’s market capitalization, and all-inclusive total industries transactions. The income approach includes level three inputs such as the Company’s calculated weighted average cost of capital and future income projections that include assumptions about revenue and gross profit growth, along with other assumptions.
 
Based on our calculation, we determined that the fair value of the Company’s equity was approximately 19% above the carrying value of the Company’s equity for our 2014 step one test. Testing under step one in 2013 and 2012 also did not indicate that the adjusted fair value of the Company’s stock was less than its book value.
 
The following table details changes in recorded goodwill (amounts in thousands):
 
Balance at January 1, 2012
  $ 54,050  
Additional goodwill related to acquisitions
    360  
Goodwill adjustments
    410  
Balance at December 31, 2013 and 2014
  $ 54,820  
 
After the annual test was completed, the Company’s stock price decreased from $7.54 on October 1, 2014 to $6.39 on December 31, 2014. Due to the decrease in the stock price, the Company noted that a goodwill impairment triggering event occurred during the fourth quarter of 2014. Therefore, the Company updated its annual goodwill impairment assessment using the two valuation methods discussed above. The methods now included fourth quarter information which incorporated the Company’s stock price at December 31, 2014 and reduced gross margins used in our discounted cash flow model projections. Based on this revised testing, there was no goodwill impairment and we determined that the fair value of the Company’s equity was approximately 13% above the carrying value of the Company’s equity.
 
Refer to Note 21 for further information regarding the Company’s assessment of Goodwill after considering certain subsequent events.
 
 
F21

 
9.  
Derivative Financial Instruments
 
The Company enters into various fixed rate commodity swap contracts in an effort to manage its exposure to price volatility of diesel fuel. Historically, fuel prices have been volatile because of supply and demand factors, worldwide political factors and general economic conditions. The objective of the Company in executing the hedge is to mitigate the fuel price volatility that could adversely affect forecasted cash flows and earnings related to construction contracts. Swaps are designed so that the Company receives or makes payments based on a differential between fixed and variable prices for off-road ultra-low sulfur diesel (“ULSD”). The Company has designated its commodity derivative contracts as cash flow hedges designed to achieve more predictable cash flows, as well as to reduce its exposure to price volatility. While the use of derivative instruments limits the downside risk of adverse price movements, they also limit future benefits from reductions in costs as a result of favorable market price movements.
 
All of the Company’s outstanding derivative financial instruments are recognized in the balance sheet at their fair values. The Company has a master netting arrangement with the counterparty; however, the gross amounts are recorded on the balance sheet. All changes in the fair value of outstanding derivatives, except any ineffective portion, are recorded in accumulated other comprehensive income until earnings are impacted by the hedged transaction. Amounts in accumulated other comprehensive income are reclassified to earnings when the related hedged items affect earnings or the anticipated transactions are no longer probable. All items included in accumulated other comprehensive income are at the corporate level, and no portion is attributable to noncontrolling interests.
 
At December 31, 2014 and 2013, the accumulated other comprehensive (loss) income consisted of unrecognized loss of $0.1 million and unrecognized gain of $0.1 million, respectively, representing the unrealized change in fair value of the effective portion of the Company’s commodity contracts, designated as cash flow hedges, as of the balance sheet date. For the years ended December 31, 2014, 2013 and 2012, the Company recognized pre-tax net realized cash settlement losses on commodity contracts of over $0.1 million, gains of less than $0.1 million and losses of less than $0.1 million, respectively.
 
At December 31, 2014, the Company had hedged its exposure to the variability in future cash flows from forecasted diesel fuel purchases totaling 0.1 million gallons. The monthly volumes hedged range from 10,000 gallons to 15,000 gallons over the period from January 2015 to August 2015 at fixed prices per gallon ranging from $2.75 to $2.79. Due to the recent decline in oil and fuel prices, the Company has not entered into any new derivative instruments.
 
The derivative instruments are recorded on the consolidated balance sheet at fair value as follows (amounts in thousands):
 
   
As of December 31,
 
Balance Sheet Location
 
2014
   
2013
 
Derivative assets:
               
Deposits and other current assets
 
$
-
   
$
109
 
Other assets, net
   
-
     
8
 
   
$
-
   
$
117
 
                 
Derivative liabilities:
               
Other current liabilities
 
$
(101
)
 
$
-
 
Other long-term liabilities
   
-
     
-
 
   
$
(101
)
 
$
-
 
 
The following table summarizes the effects of commodity derivative instruments on the consolidated statements of operations and comprehensive income (loss) (in thousands):
 
   
Years Ended December 31,
 
   
2014
   
2013
   
2012
 
Increase (decrease) in fair value of derivatives included in other comprehensive income (loss) (effective portion)
  $ (218 )     $ 109       $ 231  
Realized gain (loss) included in cost of revenues (effective portion)
    (137 )       48         (66 )
Increase (decrease) in fair value of derivatives included in cost of revenues (ineffective portion)
    -         -         -  
 
The Company’s derivative instruments contain certain credit-risk-related contingent features which apply both to the Company and to the counterparties. The counterparty to the Company’s derivative contracts is a high credit quality financial institution.
 
 
F22

 
Fair Value
 
The Company’s swaps are valued based on a discounted future cash flow model. The primary input for the model is the forecasted prices for ULSD. The Company’s model is validated by the counterparty’s fair value statements. The swaps are designated as Level 2 within the valuation hierarchy. Refer to Note 1 for a description of the inputs used to value the information shown above.
 
At December 31, 2014 and 2013, the Company did not have any derivative assets or liabilities measured at fair value on a recurring basis that meet the definition of Level 1 or Level 3 fair value inputs.
 
 
10.  
Changes in Accumulated Other Comprehensive (Loss) Income by Component
 
The changes in the balances of each component of accumulated other comprehensive (loss) income, net of tax, which is included as a component of stockholders’ equity, are as follows (amounts in thousands):
 
   
Twelve
Months Ended
December 31,
2014 (*)
 
   
Unrealized Gain
and Loss on Cash
Flow Hedges
 
Beginning Balance
  $ 117  
Other comprehensive loss before reclassification
    (355 )
Amounts reclassified from accumulated other comprehensive income
    137  
Net current-period other comprehensive loss
    (218 )
Ending Balance
  $ (101 )
 
(*) Amounts in parentheses represent reductions to accumulated other comprehensive (loss) income.
 
 
F23

 
The significant amounts reclassified out of each component of accumulated other comprehensive (loss) income are as follows (amounts in thousands):
 
   
Amount Reclassified From
Accumulated Other Comprehensive
(Loss) Income (*)
     
   
Twelve Months Ended December 31,
     
Details About Accumulated Other
Comprehensive (Loss) Income Components
 
2014
   
2013
   
2012
   
Statement of
Operations Classification
Realized gains on available-for sale securities
 
$
-
   
$
 90
   
$
 785
   
Gain on sale of securities and other
Less: Income tax expense
   
-
     
(33
)
   
 (275
)
 
Income tax (expense)
Tax valuation allowance
   
-
     
33
     
-
    benefit
Total reclassification related to available-for-sale securities
 
$
-
   
$
 90
   
$
 510
   
Net income (loss)
                             
Realized gains (losses) on cash flow hedges
 
$
(137
)
 
$
48
   
$
 (66
)
 
Cost of revenues
Less: Income tax (expense) benefit
 
 
-
     
(17
)
   
 23
   
Income tax (expense)
Tax valuation allowance
   
-
     
17
     
-
   
benefit
Total reclassification related to cash flow hedges
 
$
 (137
)
 
$
 48
   
$
 (43
)
 
Net income (loss)
 
(*) Amounts in parentheses represent reductions to earnings in the statement of operations.
 
11.
Line of Credit and Long-Term Debt
 
Long-term debt consists of the following (in thousands):
 
   
As of December 31,
 
   
2014
   
2013
 
Credit facility
  $ 34,601     $ 7,808  
Mortgage due monthly through June 2016
    116       189  
Notes payable for transportation and construction equipment
    3,269       468  
      37,986       8,465  
Less current maturities of long-term debt
    (965 )     (134 )
Total long-term debt
  $ 37,021     $ 8,331  
 
Line of Credit Facility
 
On October 31, 2007, the Company and its subsidiaries entered into a new credit facility (“Credit Facility”) with Comerica Bank with a maturity date of October 31, 2012. In December 2009, the Credit Facility was amended to permit the acquisition of RLW and in November 2011, the Credit Facility was amended to extend the maturity date to September 30, 2016. The Credit Facility is secured by all assets of the Company, other than proceeds and other rights under our construction contracts, which are pledged to our bond surety.
 
 
F24

 
The Credit Facility is subject to our compliance with certain covenants, including financial covenants relating to leverage, tangible net worth and asset coverage. The Credit Facility contains restrictions on the Company’s ability to:
 
·
Make distributions and dividends;
·
Incur liens and encumbrances;
·
Incur further indebtedness;
·
Guarantee obligations;
·
Dispose of a material portion of assets or merge with a third party;
·
Make acquisitions; and
·
Make investments in securities.
 
At the end of the second quarter of 2013, the Company was not in compliance with the leverage ratio financial covenant. On August 8, 2013, the Company obtained a Waiver and Third Amendment to Credit Agreement with its lender which waived the noncompliance with the leverage ratio financial covenant as of June 30, 2013 and provided a less restrictive leverage ratio covenant requirement. In addition, the waiver amended the existing borrowing interest fee schedule and increased borrowing rates by 100 basis points to 4.25% effective June 30, 2013.
 
At the end of the fourth quarter of 2013, the Company was not in compliance with the minimum tangible net worth and the leverage ratio financial covenants. As a result, subsequent to year end, the Company obtained a Waiver and Fourth Amendment to Credit Agreement (the “Fourth Amendment”) with its lender which waived the noncompliance with the financial covenants as of December 31, 2013 and provided less restrictive covenant requirements. The Fourth Amendment also imposed liquidity thresholds that the Company is required to meet in 2014. Refer to the discussion below of our revised amendment which eased our required liquidity thresholds.
 
Among other things, the Fourth Amendment reduced the borrowings available to $40 million from the previously available $50 million and has eliminated the option to increase the Credit Facility by an additional $50 million. The Fourth Amendment also modified the existing borrowing interest fee schedule and increased borrowing rates by 50 basis points to 4.75% effective December 31, 2013. In addition, if certain liquidity thresholds are not met in 2014 the interest rate may increase 200 basis points and continue to increase 100 basis points every quarter after 2015 until such thresholds are met. Furthermore, the Fourth Amendment requires the payment of a quarterly commitment fee of 0.75% per annum, which is an increase of 25 basis points, on unused availability.
 
On April 29, 2014, the Company obtained an amendment (the “Fifth Amendment”) with our bank which removed a requirement that we raise $20 million of new equity capital by September 30, 2014, in addition to raising $10 million of other liquidity by June 30, 2014, provided that we raise $10 million of new equity capital by May 30, 2014. As discussed below, the Company raised $14.0 million and the cash was used to repay a portion of our outstanding indebtedness under the Credit Facility. The equity raise did not reduce the Company’s borrowing capacity.
 
On September 5, 2014, the Company and its lender amended the Credit Facility (the “Sixth Amendment”) which accomplished the following:
 
·
Removed the prohibition against acquisitions and amended the definition of Permitted Acquisition in the Credit Agreement to provide that the Company may, without the lender's consent, but subject to certain restrictions, acquire another entity or its assets for a price of up to $8 million payable in shares of the Company's common stock.
·
Modified the Company’s Tangible Net Worth requirement.
·
Eliminated the covenant which capped losses per quarter.
·
Changed the monthly Covenant Compliance Reports to quarterly reports.
 
As a result of the fourth quarter loss, the Company was not in compliance with the tangible net worth covenant related to the Company’s Credit Facility at December 31, 2014. Refer to Note 21 for the subsequent events related to the resolution of our noncompliance with this debt covenant.
 
At December 31, 2014 and 2013, the Company had $34.6 million and $7.8 million outstanding under the Credit Facility, respectively, and the aggregate amount of letters of credit outstanding under the Credit Facility was $3.0 million and $2.0 million, respectively, which reduces availability under the Credit Facility. Availability under the Credit Facility was, therefore, $2.4 million and $30.2 million at December 31, 2014 and 2013, respectively.
 
 
F25

 
Mortgage
 
In 2001, TSC completed the construction of a headquarters building and financed it principally through a mortgage of $1.1 million on the land and facilities, at a floating interest rate, which at December 31, 2014 was 3.5% per annum, repayable over 15 years with a prepayment penalty. The outstanding balance on this mortgage was $0.1 million at December 31, 2014.
 
Notes Payable for transportation and construction equipment
 
The Company purchased and financed various transportation and construction equipment to enhance the Company’s fleet of equipment. The total long-term notes payable related to the purchase of financed equipment was $3.3 million and $0.5 million at December 31, 2014 and 2013, respectively. The purchases have payment terms ranging from 3 to 5 years and the associated interest rates range from 3.12% to 6.29%.
 
Maturities of Debt
 
The Company’s long-term obligations mature in future years as follows (amounts in thousands):
 
Years Ending
December 31,
 
Amount
 
2015
  $ 965  
2016
    35,499  
2017
    710  
2018
    553  
2019
    259  
Thereafter
    -  
    $ 37,986  
 
12.
Income Taxes and Deferred Tax Asset/Liability
 
The Company’s policy is to recognize interest related to any underpayment of taxes as interest expense, and penalties as administrative expenses. No interest or penalties have been accrued at December 31, 2014 and 2013, and interest and penalties for the year ended December 31, 2012 were not significant. The Company’s U.S. federal income tax returns for 2011 and later years are open and subject to examination by the I.R.S. In addition, the Company’s state income tax returns for 2010 and later years are open and subject to examination.
 
Current income tax expense represents federal and state income tax paid or expected to be payable for the years shown in the consolidated statements of operations. The income tax expense (benefit) in the accompanying consolidated financial statements consists of the following (amounts in thousands):
 
   
Years Ended December 31,
 
   
2014
   
2013
   
2012
 
Current tax expense (benefit)
  $ 632     $ (3,928 )   $ 588  
Deferred tax expense (benefit)
    -       5,150       (1,167 )
Total tax expense (benefit)
  $ 632     $ 1,222     $ (579 )
 
 
F26

 

Deferred tax assets and liabilities consist of the following (amounts in thousands):
 
   
As of December 31,
 
   
2014
   
2013
 
   
Current
   
Long
Term
   
Current
   
Long
Term
 
Assets related to:
                       
Accrued compensation and other
  $ 1,059     $ 809     $ 265     $ 451  
Amortization and impairment of goodwill
    -       10,816       -       11,108  
Accreted interest to put
    -       -       -       985  
Contingency on lawsuit
    -       -       -       106  
Noncontrolling interest
    -       2,326       -       1,439  
Deferred revenue
    125       -       6,993       -  
Revaluation of put/call liabilities
    -       8,471       -       5,127  
Net operating loss carryforwards
    -       27,172       -       18,302  
Valuation allowance for deferred tax assets
    (1,184 )     (35,393 )     (7,258 )     (23,773 )
Liabilities related to:
                               
Depreciation of property and equipment
    -       (14,186 )     -       (12,669 )
Other
    -       (15 )     -       (1,076 )
Net asset
  $ -     $ -     $ -     $ -  
 
The income tax provision (benefit) differs from the amount using the statutory federal income tax rate of 35% for the following reasons (amounts in thousands):
 
   
Years Ended December 31,
 
   
2014
   
2013
   
2012
 
   
Amount
   
%
   
Amount
   
%
   
Amount
   
%
 
Tax expense (benefit) at the U.S. federal statutory rate
  $ (1,608 )     35.0 %   $ (24,081 )     35.0 %   $ 5,997       35.0 %
State tax based on income, net of refunds and federal benefits
    (155 )     3.4       (1,280 )     1.8       (58 )     (0.3 )
Taxes on subsidiaries’ and joint ventures’ earnings allocated to noncontrolling interests owners
    (2,365 )     51.5       (1,375 )     2.0       (5,938 )     (34.7 )
Tax benefits of Domestic Production Activities Deduction
    -               -       -       (84 )     (0.5 )
Impairment associated with goodwill that is not amortizable for tax
    -               -       -       -       -  
Valuation Allowance
    4,152       (90.4 )     28,215       (41.0 )     -       -  
Reduction of tax receivable
    524       (11.4 )     -       -       -       -  
Non-taxable interest income
    -               (195 )     0.3       (529 )     (3.1 )
Other permanent differences 
    84       (1.9 )     (62 )     0.1       33       0.2  
Income tax expense (benefit)
  $ 632       (13.8 )%   $ 1,222       (1.8 )%   $ (579 )     (3.4 )%
 
 
F27

 
We have federal and state income tax net operating loss (“NOL”) carryforwards of $73.1 million and $36.4 million, which will expire at various dates in the next 20 years for U.S. federal income tax and in the next 6 to 20 years for the various state jurisdictions where we operate. Such NOL carryforwards expire as follows (amounts in thousands):
 
Year
 
Amount
 
2020
  $ 15  
2021
    50  
2028
    8,744  
2029
    3,410  
2033
    70,003  
2034
    27,312  
Total
  $ 109,534  
 
Management assesses the available positive and negative evidence to estimate if sufficient future taxable income will be generated to use the existing deferred tax assets. A significant piece of objective negative evidence evaluated was the cumulative loss incurred over the three-year period ended December 31, 2014. The cumulative three-year period loss that remained in the fourth quarter 2014 was the result of write-downs recorded during the year. Such objective evidence limits the ability to consider other subjective evidence such as our projections for future growth. On the basis of this evaluation, as of December 31, 2014, a valuation allowance of $36.6 million has been recorded on the net deferred tax assets including federal and state net operating losses as they are not likely to be realized. The amount of the deferred tax asset considered realizable, however, could be adjusted if objective negative evidence or cumulative losses are no longer present and additional weight may be given to subjective evidence such as our projections for growth.
 
If our assumptions change and we determine we will be able to realize these NOLs, the tax benefits relating to any reversal of the valuation allowance on deferred tax assets as of December 31, 2014, will be accounted for as follows: approximately $34.0 million will be recognized as a reduction of income tax expense and $2.6 million will be recorded as an increase in equity.
 
As a result of certain realization requirements by GAAP, the table of deferred tax assets and liabilities shown above does not include certain deferred tax assets as of December 31, 2014, and December 31, 2013, that arose directly from (or the use of which was postponed by) tax deductions related to equity compensation that are greater than the compensation recognized for financial reporting. Equity will be increased by $16,000 if and when such deferred tax assets are ultimately realized.
 
On September 13, 2013, the U.S. Treasury Department and the I.R.S. issued final regulations that address costs incurred in acquiring, producing, or improving tangible property (the "tangible property regulations"). The tangible property regulations are generally effective for tax years beginning on or after January 1, 2014. The Company intends to adopt the tax treatment of expenditures to improve tangible property and the capitalization of inherently facilitative costs to acquire tangible property as of January 1, 2014. The tangible property regulations will require the Company to make additional tax accounting method changes as of January 1, 2014; however, management does not anticipate the impact of these changes to be material to the Company’s consolidated financial position, its results of operations, or both.
 
As a result of the Company’s analysis, management has determined that the Company does not have any material uncertain tax positions.
 
13.  
Commitments and Contingencies
 
Employment Agreements
 
At December 31, 2014, the Company’s Chief Executive Officer, its Executive Vice Presidents and certain executive officers of its subsidiaries had employment agreements which provided for payments of annual salary, deferred salary, incentive compensation and certain benefits if their employment is terminated without cause. The Company has also entered into change of control agreements with certain officers providing for additional payments in the event that their employment is terminated without cause just before or within two years after a change of control of the Company.
 
 
F28

 
Self-Insurance
 
The Company is self-insured for employee health claims. Its policy is to accrue the estimated liability for known claims and for estimated claims that have been incurred but not reported as of each reporting date. In order to reduce the Company’s exposure to large health claims, it has obtained stop-loss coverage for the policy period as follows:
 
·
Coverage for medical and prescription drug claim amounts in excess of $55,000 for RLW and JBC, and $95,000 for all other entities, for each insured person within a plan year.
 
·
Combined coverage for medical and prescription drug claim amounts in excess of $5.2 million within a plan year.
 
For the years ended December 31, 2014, 2013 and 2012, the Company incurred $2.2 million, $2.4 million, and $2.0 million, respectively, in claim expenses related to this plan.
 
The Company and its subsidiaries are also self-insured for workers’ compensation, general liability, and auto claims up to $250,000, $250,000 and $50,000 per occurrence, respectively, with a maximum aggregate liability of $4.2 million combined casualty losses per year.
 
The Company’s policy is to accrue the estimated liability for known claims and for estimated workers compensation, employee health, general liability and other claims that have been incurred but not reported as of each reporting date. At December 31, 2014 and 2013, the Company had recorded an estimated liability of $2.8 million and $1.7 million, respectively, which it believes is adequate for such claims based on its claims history and actuarial studies. The Company has a safety and training program in place to help prevent accidents and injuries and works closely with its employees and the insurance company to monitor all claims.
 
The Company is required by our insurance provider to obtain and hold a standby letter of credit that serves as a guarantee by our lender to pay our insurance provider the incurred claim costs attributable to our general liability, workers compensation and automobile liability claims, up to the amount stated in the standby letter of credit, in the event that these claims were not paid by the Company. If ever demanded, the standby letter of credit would be drawn against our Credit Facility and as a result, reduces our current credit availability. Historically, this standby letter of credit has not been drawn upon. Refer to Note 11 for the amount held in our standby letter of credit at December 31, 2014 and 2013.
 
Guarantees
 
The Company obtains bonding on construction contracts through Travelers Casualty and Surety Company of America (“Travelers”). As is customary in the construction industry, the Company indemnifies Travelers for any losses incurred by it in connection with bonds that are issued. The Company has granted Travelers a security interest in accounts receivable and contract rights for that obligation.
 
The Company typically indemnifies contract owners for claims arising during the construction process and carries insurance coverage for such claims, which in the past have not been material.
 
The Company’s Certificate of Incorporation provides for indemnification of its officers and directors. The Company has a directors and officers insurance policy that limits their exposure to litigation against them in their capacities as such.
 
Litigation
 
In January 2010, a jury trial was held to resolve a dispute between RHB and a subcontractor. The jury rendered a verdict of $1.0 million against RHB, exclusive of interest, court costs and attorney’s fees. The Company recorded this verdict as an expense in the year ended December 31, 2009, but appealed this judgment. The appeal was heard by the Nevada Supreme Court, and during the quarter ended September 30, 2012, the Court upheld the original verdict against RHB. The Company recorded additional expense of $156,000 during that same period to cover court costs and attorney’s fees. Payment for the total judgment, court costs and attorney’s fees was made in October 2012, and this matter is now resolved in its entirety. There are no significant unresolved legal issues as of December 31, 2014.
 
The Company is the subject of certain other claims and lawsuits occurring in the normal course of business. Management, after consultation with legal counsel, does not believe that the outcome of these other actions will have a material impact on the financial statements of the Company.
 
 
F29

 
Purchase Commitments
 
To manage the risk of changes in material prices and subcontracting costs used in tendering bids for construction contracts, most of the time, we obtain firm quotations from suppliers and subcontractors before submitting a bid. These quotations do not include any quantity guarantees. As soon as we are advised that our bid is the lowest, we enter into firm contracts with most of our materials suppliers and sub-contractors, thereby mitigating the risk of future price variations affecting the contract costs.
 
14.  
Operating Leases
 
The Company leases certain property and equipment under cancelable and non-cancelable agreements including office space.
 
Minimum annual rentals for all operating leases having initial non-cancelable lease terms in excess of one year are as follows (amounts in thousands):
 
Years Ending December 31,
 
Amount
 
2015
  $ 1,550  
2016
    1,359  
2017
    1,232  
2018
    1,251  
2019
    1,225  
Thereafter
    2,176  
Total future minimum rental payments
  $ 8,793  
 
Total rent expense for all operating leases amounted to approximately $1.6 million, $0.9 million and $1.2 million in fiscal years 2014, 2013 and 2012, respectively.
 
15.  
Net Loss Per Share Attributable to Sterling Common Stockholders
 
Basic net loss per share attributable to Sterling common stockholders is computed by dividing net loss attributable to Sterling common stockholders by the weighted average number of common shares outstanding during the period. Diluted net loss per common share attributable to Sterling common stockholders is the same as basic net loss per share attributable to Sterling common stockholders but assumes the exercise of dilutive unvested common stock and stock options using the treasury stock method. The following table reconciles the numerators and denominators of the basic and diluted per common share computations for net loss attributable to Sterling common stockholders for 2014, 2013 and 2012 (amounts in thousands, except per share data):
 
   
Years Ended December 31,
 
   
2014
   
2013
   
2012
 
Numerator:
                 
Net loss attributable to Sterling common stockholders
  $ (9,781 )   $ (73,929 )   $ (297 )
Revaluation of noncontrolling interest put/call liability reflected in additional paid in capital or retained earnings, net of tax
    -       (7,686 )     (3,992 )
    $ (9,781 )   $ (81,615 )   $ (4,289 )
Denominator:
                       
Weighted average common shares outstanding — basic
    18,063       16,635       16,421  
Shares for dilutive stock options and warrants
    -       -       -  
Weighted average common shares outstanding and assumed
conversions— diluted
    18,063       16,635       16,421  
Basic and diluted net loss per share attributable to Sterling common stockholders
  $ (0.54 )   $ (4.91 )   $ (0.26 )
 
The Company had no options outstanding but considered antidilutive due to the option exercise price exceeding the average share market price at December 31, 2014, 2013 and 2012, respectively. In addition, 152,900, 160,206 and 109,424 shares for unvested stock and stock options were excluded from the diluted weighted average common shares outstanding in 2014, 2013 and 2012, respectively, as the Company incurred a loss in these years and the impact of such shares would have been antidilutive.
 
16.  
Stockholders’ Equity
 
Holders of common stock are entitled to one vote for each share on all matters voted upon by the stockholders, including the election of directors, and do not have cumulative voting rights. Subject to the rights of holders of any then outstanding shares of preferred stock, common stockholders are entitled to receive ratably any dividends that may be declared by the Board of Directors out of funds legally available for that purpose. Holders of common stock are entitled to share ratably in net assets upon any dissolution or liquidation after payment of provision for all liabilities and any preferential liquidation rights of our preferred stock then outstanding. Common stock shares are not subject to any redemption provisions and are not convertible into any other shares of capital stock. The rights, preferences and privileges of holders of common stock are subject to those of the holders of any shares of preferred stock that may be issued in the future.
 
 
F30

 
The Board of Directors may authorize the issuance of one or more classes or series of preferred stock without stockholder approval and may establish the voting powers, designations, preferences and rights and restrictions of such shares. No preferred shares have been issued.
 
Treasury and Forfeited Shares
 
In October 2008, the Company announced a share-repurchase program to purchase up to $5 million in shares of common stock. In August 2010, the Company announced an increase to the share-repurchase program to purchase an additional $5 million in shares of common stock, for a total up to $10 million. The specific timing and amount of repurchase will vary based on market conditions, securities law limitations and other factors. There were no shares repurchases in 2014, 2013 and 2012 related to the share-repurchase program.
 
The Company accounts for the repurchase of treasury shares under the cost method. When shares are repurchased, cash is paid and the treasury stock account is debited for the price paid. Under the cost method, retirement of treasury stock would result in a debit to the common stock account for the original par value, a debit to additional paid-in capital for the excess between the par value and the original sales price, a debit to retained earnings for any excess amounts paid above the original sales price and a credit to the treasury stock account for the price paid.
 
Forfeited shares are generally the result of employee separation from the Company. There were forfeitures of 20,412 and 8,944 shares in 2014 and 2013, respectively, and no shares forfeited in 2012. Such stock is held briefly as treasury stock and canceled during the year. At December 31, 2014 and 2013, there was no treasury stock held by the Company.
 
Upon the vesting of unvested common stock (or restricted stock) the Company may withhold shares, based on the employee’s election, in order to satisfy federal tax withholdings. The shares held by the Company are considered constructively retired and are retired shortly after withholding. The Company then remits the withholding taxes required by the taxing agencies. During 2014 and 2013 there were 8,120 and 6,652 shares withheld for tax purposes and retired.
 
Stock-based Compensation and Grants
 
The Company has a stock-based incentive plan that is administered by the Compensation Committee of the Board of Directors (the “2001 Plan”). The 2001 Plan is in effect until May 2021 as a result of a May 2011 amendment to extend its term for an additional ten years. The 2001 Plan provides for the issuance of stock awards for up to 1,900,000 shares of the Company’s common stock. The Compensation Committee may reward employees and non-employees with various types of awards including but not limited to warrants, stock options, common stock, and unvested common stock (or restricted stock) vesting on service, performance or market criteria.
 
At December 31, 2014, there were 997,377 shares of common stock available under the 2001 Plan. All 997,377 shares under the plan are available for issuance pursuant to future stock-based compensation awards.
 
There were no options outstanding at December 31, 2014 and 2013 and no shares are, or will be, available for grant under the Company’s other option plans, all of which have been terminated.
 
Common Stock Awards
 
The following table summarizes the Company’s service-based share compensation awards:
 
   
Number of Shares
   
Weighted Average
Fair Value
Per Share
 
Nonvested at January 1, 2012
    71,469     $ 14.68  
Granted
    149,704       9.75  
Vested
    (34,543 )     13.05  
Forfeited
    -       -  
Nonvested at December 31, 2012
    186,630       11.03  
Granted
    60,032       9.74  
Vested
    (56,602 )     10.57  
Forfeited
    (8,944 )     13.57  
Nonvested at December 31, 2013
    181,116       10.61  
Granted
    61,957       9.05  
Vested
    (73,190 )     6.88  
Forfeited
    (20,412 )     11.66  
Nonvested at December 31, 2014
    149,471       11.65  
 
 
F31

 
In 2014, 2013 and 2012, several key employees were granted an aggregate total of 18,536, 25,207 and 118,774 shares of unvested common stock, respectively, with a weighted average fair value per share of $11.38, $9.30 and $9.76 per share, respectively, resulting in compensation expense of $0.2 million, $0.2 million and $1.2 million, respectively, to be recognized ratably over a three- or five-year restriction period.
 
The 2001 plan provides for unvested (or restricted) and vested common stock grants, and pursuant to non-employee director compensation arrangements, non-employee directors of the Company were awarded unvested stock with one-year vesting as follows:
 
   
Years Ended December 31,
 
   
2014
   
2013
   
2012
 
Shares awarded to each non-employee director
    6,203       4,975       5,155  
Total shares awarded
    43,421       34,825       30,930  
Average grant-date market price per share
  $ 8.06     $ 10.06     $ 9.70  
Total compensation cost attributable to shares awarded
  $ 350,000     $ 350,000     $ 300,000  
Compensation cost recognized related to current and prior year awards
  $ 316,750     $ 333,499     $ 283,333  
 
During the year ended December 31, 2014, a director of the Company retired and forfeited 6,203 unvested shares. The amortized expense was adjusted for this forfeiture.
 
In addition to the service based compensation awards discussed above, the Company also awarded performance-based awards. There were no performance-based shares awarded in 2012. In 2013, the Company issued 100,000 shares of unvested common stock to the Company’s CEO. These shares were to vest on March 31, 2018 subject to the satisfaction of a performance condition. In 2014, there were a total of 7,500 performance-based shares issued. In order to recognize compensation expense for these performance based shares, the Company must assess, at each reporting period, whether it is probable that the performance condition will be met. These shares must also be re-valued at each reporting period until they vest. At December 31, 2014, the Company assessed that it would not be probable that the performance condition would be met, as such; no expense was incurred during the year.
 
At December 31, 2014, total unrecognized compensation cost related to unvested common stock was $0.8 million. This cost is expected to be recognized over a weighted average period of 1.4 years. Compensation expense for stock options and unvested common stock (or restricted stock) grants was $0.8 million (with no tax benefit) in each of 2014 and 2013 and $0.7 million ($0.5 million after tax benefit of 35.0%) in 2012. Proceeds received by the Company from the exercise of options in 2014, 2013 and 2012 were less than $0.1 million for each of these years. The Company also awards common stock as part of its incentive plan with no service or performance vesting requirements. There were no such shares awarded in 2014 and 2012 and 9,521 shares with a grant date fair value of $0.1 million awarded in 2013 which was treated as compensation expense in 2013.
 
Stock Option Awards
 
The following tables summarize the stock option activity under the 2001 Plan and previously active plans:
 
   
2001 Plan
 
   
Shares
   
Weighted Average
Exercise Price
 
Outstanding at December 31, 2012
    22,200     $ 3.08  
Exercised
    (8,500 )     3.08  
Expired/forfeited
    (6,200 )     3.07  
Outstanding at December 31, 2013
    7,500       3.10  
Exercised
    (4,000 )     3.10  
Expired/forfeited
    (3,500 )     3.10  
Outstanding at December 31, 2014
    -       -  
 
   
Number
of Shares
   
Aggregate
Intrinsic Value
 
Total options exercised during 2014
    4,000     $ 21,911  
 
 
F32

 
For options exercised during 2014, aggregate intrinsic value represents the total pre-tax intrinsic value based on the difference between Company’s closing stock price on the day of exercise and the exercise price multiplied by the shares received upon exercise. There were no options outstanding as of December 31, 2014.
 
At December 31, 2014, there was no unrecognized stock-based compensation expense related to stock options.
 
Stock Offering
 
On April 29, 2014, an amended “shelf” registration statement filed by the Company with the SEC became effective. Under the amended shelf registration statement, the Company may offer from time to time any combination of securities described in the prospectus in one or more offerings up to a total of $80 million. The securities described in the prospectus include common and preferred stock, depository shares, debt securities, warrants entitling the holders to purchase one or more classes or series of these securities or units consisting of two or more of these issuances, classes or series of securities. Net proceeds from the sales of the offered securities may be used for working capital needs, capital expenditures and other expenditures related to general corporate purposes, including future acquisitions.
 
On May 6, 2014, the Company closed a public offering with D.A. Davidson & Co. as sole underwriter (the “Underwriter”), pursuant to which the Underwriter purchased from the Company 2,100,000 shares of the Company’s common stock at a price of $6.90 per share. The net proceeds of $14.0 million from the offering, after deducting underwriting discounts and offering expenses, was used to repay a portion of the indebtedness outstanding under our Credit Facility.
 
17.  
Employee Benefit Plans
 
The Company maintains two defined contribution profit-sharing plan (401(k) plans) covering substantially all non-union persons employed by the Company, whereby employees may contribute a percentage of compensation, limited to maximum allowed amounts under the Internal Revenue Code. The Plans provide for discretionary employer contributions, the level of which, if any, may vary by subsidiary and is determined annually by each company’s board of directors. The Company made aggregate matching contributions of $1.3 million, $1.1 million and $1.3 million for the years ended December 31, 2014, 2013 and 2012, respectively.
 
The Company contributes to a number of multiemployer defined benefit pension plans under the terms of collective-bargaining agreements that cover its union-represented employees. The risks of participating in these multiemployer plans are different from single-employer plans in the following aspects:
 
·
Assets contributed to the multiemployer plan by one employer may be used to provide benefits to employees of other participating employers. If a participating employer stops contributing to the plan, the unfunded obligations of the plan may be borne by the remaining participating employers.
 
·
If the Company chooses to stop participating in some of its multiemployer plans, the Company may be required to pay those plans an amount based on the underfunded status of the plan, referred to as a withdrawal liability.
 
 
F33

 
The following table presents our participation in these plans (amounts in thousands):
 
Pension Trust
  Identification  
Pension Protection
Act (“PPA”)
Certified Zone
Status1
 
FIP / RP
Status
Pending /
 
Contributions
   
Surcharge
 
Expiration
Date of
Collective
Bargaining
Fund   Number  
2014
 
2013
  Implemented2  
2014
   
2013
   
2012
    Imposed   Agreement3
Pension Trust Fund for Operating Engineers Pension Plan
  94-6090764  
Red
 
Red
 
Yes
  $ 1,757     $ 1,654     $ 508    
No
 
6/30/2016
Laborers Pension Trust for Northern California
  94-6277608  
Yellow
 
Yellow
 
Yes
    1,447       897       431    
No
 
6/30/2019
Carpenter Funds Administrative Office
  94-6050970  
Red
 
Red
 
Yes
    1,015       759       47    
No
 
6/30/2019
Cement Mason Pension Trust Fund For Northern California
  94-6277669  
Yellow
 
Yellow
 
Yes
    322       517       265    
No
 
6/30/2016
All other funds (84)4
                    6,267       2,608       4,290        
Various
           
Total Contributions:
  $ 10,808     $ 6,435     $ 5,541          
 
1
The most recent PPA zone status available in 2014 and 2013 is for the plan’s year-end during 2013 and 2012, respectively. The zone status is based on information that we received from the plan and is certified by the plan’s actuary. Among other factors, plans in the red zone are generally less than 65 percent funded, plans in the orange zone are less than 80 percent funded and have an Accumulated Funding Deficiency in the current year or projected into the next six years, plans in the yellow zone are less than 80 percent funded, and plans in the green zone are at least 80 percent funded.
2
Indicates whether the plan has a financial improvement plan (“FIP”) or a rehabilitation plan (“RP”) which is either pending or has been implemented.
3
Lists the expiration date(s) of the collective-bargaining agreement(s) to which the plans are subject.
4
These funds include multiemployer plans for pensions and other employee benefits. The total individually insignificant multiemployer pension costs contributed were $903,000, $603,000 and $466,000 for 2014, 2013 and 2012, respectively, and are included in the contributions to all other funds along with contributions to other types of benefit plans. Other employee benefits include certain coverage for medical, prescription drug, dental, vision, life and accidental death and dismemberment, disability and other benefit costs.
 
The work the Company performed in California has increased resulting in an increased contribution to the Laborers Pension Trust for Northern California and the Carpenters Fund Administrative Office during 2014, 2013 and 2012.
 
We currently have no intention of withdrawing from any of the multi-employer pension plans in which we participate.

 
 
F34

 
18.  
Concentration of Risk and Enterprise Wide Disclosures
 
The following table shows contract revenues generated from the Company’s customers that accounted for more than 10% of revenues (amounts in thousands):
 
   
Years Ended December 31,
 
   
2014
    2013     2012  
   
Amount
   
%
   
Amount
   
%
   
Amount
   
%
 
Utah Department of Transportation (“UDOT”)
  $ *       * %   $ *       * %   $ 100,658       16.0 %
California Department of Transportation (“Caltrans”)
    97,637       14.5       92,159       16.6       94,171       15.0  
*Represents less than 10% of revenues
 
At December 31, 2014, Foursquare Properties Inc. owed $8.5 million and TxDOT owed $7.6 million to the Company, which is greater than 10% of contract receivables. At December 31, 2013, Central Texas Mobility Constructors (“CTMC”) owed $16.3 million, Foursquare Properties Inc. owed $11.4 million and City of Honolulu owed $10.0 million to the Company, which was greater than 10% of contract receivables. At December 31, 2012, North Texas Tollway Authority (“NTTA”) owed $8.8 million to the Company, which was greater than 10% of contract receivables.
 
The Company’s revenue and receivables are entirely derived from the construction of U.S. projects and all of the Company’s assets are held domestically within the U.S.
 
A portion of our labor force is subject to collective bargaining agreements. Refer to Note 17 for further information regarding this concentration of risk.
 
19.  
Related Party Transactions
 
The Company has limited related party transactions. The most material transactions relate to the Company’s RLW subsidiary and its executive management who own or have an ownership interest in certain real estate and other companies. RLW has historically performed construction contracts, leased properties, or has provided professional and other services for entities owned by the executive managers of RLW. The total RLW related party revenue related to construction contracts totaled $0.5 million, $0.2 million and less than $0.1 million in 2014, 2013 and 2012, respectively. The total RLW related party billings for professional and other services, which include accounting, payroll, reimbursement for computer and postage usage, provided by RLW was $0.9 million and $1.0 million in 2013 and 2012, respectively. RLW leases its main office and equipment maintenance shop for its Utah operations for an annual cost of approximately $0.2 million each, plus annual common area maintenance charges of less than $0.1 million each. The office and shop leases expire in 2022. RLW had other miscellaneous related party transactions which aggregated to less than $0.2 million in each 2014, 2013 and 2012 year.
 
The Company had individually immaterial miscellaneous transactions with related parties that totaled $0.4 million, during each year 2014, 2013 and 2012.
 
During 2012, the Company entered into a business combination with Richard Buenting, the President and Chief Executive Officer of RHB. Refer to Note 2 for a description of the related party transaction.
 
An independent member of senior management of the Company reviewed all related party sales and purchases before they were transacted.
 
 
F35

 
20.  
Quarterly Financial Information
 
The following table summarizes the unaudited quarterly results of operations for 2014 and 2013 (amounts in thousands, except per share data):
 
   
2014 Quarters Ended (unaudited)
       
   
March 31
   
June 30
   
September 30
   
December 31
   
Total
 
Revenues
  $ 134,538     $ 194,806     $ 189,275     $ 153,611     $ 672,230  
Gross profit
    7,869       12,499       8,356       3,697       32,421  
Income (loss) before income taxes and earnings attributable to noncontrolling interests
    480       2,473       (1,671 )     (5,875 )     (4,593 )
Net income (loss) attributable to Sterling common stockholders
    205       1,200       (3,935 )     (7,251 )     (9,781 )
Net income (loss) per share attributable to Sterling common stockholders:
                                       
Basic
  $ 0.01     $ 0.07     $ (0.21 )   $ (0.39 )   $ (0.54 )
Diluted
    0.01       0.07       (0.21 )     (0.39 )     (0.54 )
 
   
2013 Quarters Ended (unaudited)
       
   
March 31
   
June 30
   
September 30
   
December 31
   
Total
 
Revenues
  $ 111,035     $ 133,350     $ 185,935     $ 125,916     $ 556,236  
Gross profit (loss)
    1,385       (16,635 )     8,359       (23,053 )     (29,944 )
Income (loss) before income taxes and earnings attributable to noncontrolling interests
    (7,219 )     (25,967 )     1,715       (37,333 )     (68,804 )
Net loss attributable to Sterling common stockholders
    (4,580 )     (17,025 )     (189 )     (52,135 )     (73,929 )
Net loss per share attributable to Sterling common stockholders:
                                       
Basic
  $ (0.39 )   $ (0.93 )   $ (0.06 )   $ (3.52 )   $ (4.91 )
Diluted
    (0.39 )     (0.93 )     (0.06 )     (3.52 )     (4.91 )
 
The Company’s operating revenues tend to be somewhat higher in the summer months which are typically due to warmer and dryer weather conditions. Our second and third quarter revenues and results of operations typically reflect these seasonal trends. However, from time to time, the Company’s operating results are significantly affected by certain transactions or events that management believes are not indicative or representative of our results.
 
During the third and fourth quarters of 2014, the Company recorded changes in estimated revenues and gross margin which resulted in net charges of $4.5 million and $9.5 million, respectively. Gross profit was depressed by downward revisions of gross profit on problem projects, the majority of which are being constructed in Texas, primarily due to spot shortages of commodities, over-stretched sub-contractors and vendors, and intense competition for craft labor. 
 
During the first, second and fourth quarters of 2013, the Company recorded changes in estimated revenues and gross margin which resulted in net charges of $4.3 million, $20.6 million and $37.7 million, respectively. A significant portion of these revisions were attributable to three projects. Furthermore, during the fourth quarter, management recorded a valuation allowance of $28.2 million on the net deferred tax assets as a result of the fourth quarter revisions mentioned above. Refer to Note 12 for our disclosure regarding income taxes and deferred assets and liabilities.
 
21.  
Subsequent Events – CEO Departure, Goodwill and Covenant Compliance
 
CEO Departure
 
On February 2, 2015, the Company announced that Peter MacKenna, formerly the Company’s President & Chief Executive Officer and a director, had left the Company effective January 31, 2015, with Paul J. Varello, the Chairman of the Board of Directors, being named acting Chief Executive Officer effective February 1, 2015.
 
The Company expensed $1.8 million in February 2015 related to severance received by Mr. MacKenna.
 
 
F36

 
Goodwill
 
On January 27, 2015, the Company announced its preliminary fourth quarter and full year 2014 results and that the Company was not in compliance with the Credit Facility’s tangible net worth covenant.
 
The Company believes these announcements negatively impacted the Company’s stock price which decreased from $5.52 on January 26, 2015 to $3.97 on January 27, 2015 and has not yet recovered. Due to the decrease in the stock price, the Company noted that a goodwill impairment triggering event may have occurred in January 2015.
 
Covenant Compliance
 
As a result of the fourth quarter loss, the Company was not in compliance with the tangible net worth covenant related to the Company’s Credit Facility at December 31, 2014. On March 12, 2015, the Company obtained a waiver and amendment (the “Seventh Amendment”) which included the following key modifications:
 
·
A reduction in our availability of $5 million for total availability of $35 million as of March 12, 2015;
 
·
A reduction in our availability of $10 million at June 1, 2015, for total availability of $25 million;
 
·
A reduction in our availability of $10 million at September 1, 2015, for total availability of $15 million;
 
·
An increase in our annual interest rate from the prime rate plus 150 basis points, or 4.75%, to the prime rate plus 350 basis points, or 6.75%;
 
·
The tangible net worth covenant is modified to include $11.3 million of available headroom from the $86.3 million of tangible net worth calculated at December 31, 2014;
 
·
Our first covenant test will begin at the end of April using April annualized figures; and
 
·
A fee of $0.4 million is due in four equal payments. The first payment was due upon execution of the Seventh Amendment and the second, third and fourth payments are due on June 30th, September 30th, and December 31st of 2015, respectively. However, any remaining unpaid fees are waived if at any point during the year the Company liquidates and terminates the Credit Facility a month before a payment becomes due.
 
 
F37